Loading...
HomeMy WebLinkAbout2026-01-19 I01E_03 Existing Public Safety Building Renovation Bid Pkg 1_Approve Contract, BondAGENDA ITEM: CITY OF WAUKEE, IOWA CITY COUNCIL MEETING COMMUNICATION MEETING DATE: January 19, 2026 AGENDA ITEM:Consideration of approval of a resolution approving contract and bond [Waukee Public Safety Building Renovation Project, Bid Package No. 1 – Exterior Glass and Glazing] FORMAT:Resolution SYNOPSIS INCLUDING PRO & CON: FISCAL IMPACT INCLUDING COST/BENEFIT ANALYSIS:$155,170.00 COMMISSION/BOARD/COMMITTEE COMMENT: STAFF REVIEW AND COMMENT: RECOMMENDATION: City staff recommends approving contract and bond with PDM Glass of Des Moines, IA, in the amount of $155,170.00. ATTACHMENTS: I. Proposed resolution II. Contract, Bond PREPARED BY: City Clerk Becky Schuett REVIEWED BY: I1E3 RESOLUTION 2026- RESOLUTION APPROVING CONSTRUCTION CONTRACT AND BOND FOR THE EARLY BID PACKAGE FOR EXISTING FIRE/POLICE BUILDING RENOVATION BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF WAUKEE, STATE OF IOWA: That the construction contract and bond executed and insurance coverage for the construction of certain public improvements described in general as the Early Bid Package for Existing Fire/Police Building Renovation, and as described in detail in the plans and specifications heretofore approved, and which have been signed by the Mayor and Clerk on behalf of the City be and the same are hereby approved as follows: Contractor:PDM Glass of Des Moines, IA Amount of bid:$155,170.00 Bond surety: Date of bond: Portion of project:All construction work PASSED AND APPROVED this 19th day of January, 2026. Mayor ATTEST: City Clerk Document A132® – 2019 Standard Form of Agreement Between Owner and Contractor, Construction Manager as Adviser Edition Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 1 ADDITIONS AND DELETIONS: The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. This document is intended to be used in conjunction with AIA Documents A232™–2019, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition; B132™–2019, Standard Form of Agreement Between Owner and Architect, Construction Manager as Adviser Edition; and C132™–2019, Standard Form of Agreement Between Owner and Construction Manager as Adviser. AIA Document A232™–2019 is adopted in this document by reference. Do not use with other general conditions unless this document is modified. AGREEMENT made as of the 19 day of January in the year 2026 (In words, indicate day, month, and year.) BETWEEN the Owner: (Name, legal status, address, and other information) City of Waukee Iowa 230 W Hickman Road Waukee, IA 50263 and the Contractor: (Name, legal status, address, and other information) PDM Glass 220 SE 6th Street, Suite 100 Des Moines, IA 50309 for the following Project: (Name, location, and detailed description) Waukee Existing Fire/Police Building Renovation 1300 SE La Grant Parkway, Waukee, Iowa 50263 Renovation of the existing Police/Fire Building The Construction Manager: (Name, legal status, address, and other information) Ryan Companies, US Inc. 111 E Grand Avenue, Suite 200 Des Moines, IA 50309 The Architect: (Name, legal status, address, and other information) OPN Architects 100 Court Avenue, #100 Des Moines, IA 50309 The Owner and Contractor agree as follows. Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 2 TABLE OF ARTICLES 1 THE CONTRACT DOCUMENTS 2 THE WORK OF THIS CONTRACT 3 DATE OF COMMENCEMENT AND DATES OF SUBSTANTIAL COMPLETION 4 CONTRACT SUM 5 PAYMENTS 6 DISPUTE RESOLUTION 7 TERMINATION OR SUSPENSION 8 MISCELLANEOUS PROVISIONS 9 ENUMERATION OF CONTRACT DOCUMENTS EXHIBIT A INSURANCE AND BONDS EXHIBIT B SCHEDULE EXHIBIT C SCOPE OF WORK EXHIBIT D DRAWINGS EXHIBIT E SPECIFICATIONS ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary, and other Conditions), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement, and Modifications issued after execution of this Agreement, all of which form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations, or agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 9. ARTICLE 2 THE WORK OF THIS CONTRACT The Contractor shall fully execute the Work described in the Contract Documents, except as specifically indicated in the Contract Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND DATES OF SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: (Check one of the following boxes.) [ ]The date of this Agreement. [ ]A date set forth in a notice to proceed issued by the Owner. [ X ]Established as follows: (Insert a date or a means to determine the date of commencement of the Work.) Within five (5) days of notice to proceed from Construction Manager If a date of commencement of the Work is not selected, then the date of commencement shall be the date of this Agreement. § 3.2 The Contract Time shall be measured from the date of commencement of the Work. Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 3 § 3.3 Substantial Completion of the Project or Portions Thereof § 3.3.1 Subject to adjustments of the Contract Time as provided in the Contract Documents, the date of Substantial Completion of the Work of all of the Contractors for the Project will be: (Insert the date of Substantial Completion of the Work of all Contractors for the Project.) See Exhibit B attached hereto. Contractor shall be responsible to Substantially and Finally Complete its Scope of Work within the schedule limitations set forth on Exhibit B hereto. Contractor’s Scope of Work is set forth on Exhibit C hereto. § 3.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents, if portions of the Work of all of the Contractors for the Project are to be completed prior to Substantial Completion of the entire Work of all of the Contractors for the Project, the Contractors shall achieve Substantial Completion of such portions by the following dates: Portion of Work Substantial Completion Date § 3.4 When the Work of this Contract, or any Portion Thereof, is Substantially Complete § 3.4.1 Subject to adjustments of the Contract Time as provided in the Contract Documents, the Contractor shall substantially complete the entire Work of this Contract: (Check one of the following boxes and complete the necessary information.) [ ]Not later than ( ) calendar days from the date of commencement of the Work. [ ]By the following date: § 3.4.2 Subject to adjustments of the Contract Time as provided in the Contract Documents, if portions of the Work of this Contract are to be substantially complete prior to when the entire Work of this Contract shall be substantially complete, the Contractor shall substantially complete such portions by the following dates: Portion of Work Date to be substantially complete Bid Package #01 Exterior Glass & Glazing December 14, 2026 § 3.4.3 If the Contractor fails to substantially complete the Work of this Contract, or portions thereof, as provided in this Section 3.4, liquidated damages, if any, shall be assessed as set forth in Section 4.5. ARTICLE 4 CONTRACT SUM § 4.1 The Owner shall pay the Contractor the Contract Sum in current funds for the Contractor’s performance of the Contract. The Contract Sum shall be one of the following: (Check the appropriate box.) [ X ]Stipulated Sum, in accordance with Section 4.2 below [ ]Cost of the Work plus the Contractor’s Fee, in accordance with Section 4.3 below [ ]Cost of the Work plus the Contractor’s Fee with a Guaranteed Maximum Price, in accordance with Section 4.4 below (Based on the selection above, complete Section 4.2, 4.3 or 4.4 below.) § 4.2 Stipulated Sum § 4.2.1 The Contract Sum shall be One hundred fifty-five thousand, one hundred seventy dollars and zero cents. ($ $155,170.00 ), subject to additions and deductions as provided in the Contract Documents. § 4.2.2 Alternates § 4.2.2.1 Alternates, if any, included in the Contract Sum: Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 4 Item Price § 4.2.2.2 Subject to the conditions noted below, the following alternates may be accepted by the Owner following execution of this Agreement. Upon acceptance, the Owner shall issue a Modification to this Agreement. (Insert below each alternate and the conditions that must be met for the Owner to accept the alternate.) Item Price Conditions for Acceptance § 4.2.3 Allowances, if any, included in the Contract Sum: (Identify each allowance.) Item Price § 4.2.4 Unit prices, if any: (Identify the item and state the unit price, and quantity limitations, if any, to which the unit price will be applicable.) Item Units and Limitations Price per Unit ($0.00) (Paragraphs deleted) (Table deleted) (Paragraphs deleted) (Table deleted) (Paragraphs deleted) (Table deleted) (Paragraphs deleted) (Table deleted) (Paragraphs deleted) (Table deleted) (Paragraphs deleted) § 4.5 Liquidated damages, if any: (Insert terms and conditions for liquidated damages, if any, to be assessed in accordance with Section 3.4.) If Substantial Completion is not achieved by the date specified in the Contract Documents, then Construction Manager shall pay the Owner liquidated damages in the amount of one-thousand dollars ($1,000.00) per day for each day beginning on the first day after the date specified in the Contract Documents up to but not including the Substantial Completion Date. If Final Completion is not achieved by the date specified in the Contract Documents, then Construction Manager shall pay the Owner liquidated damages in the amount of one-thousand dollars ($1,000.00) per day for each day beginning on the first day after the date specified in the Contract Documents up to but not including the Final Completion Date. § 4.6 Other: (Insert provisions for bonus, cost savings or other incentives, if any, that might result in a change to the Contract Sum.) Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 5 ARTICLE 5 PAYMENTS § 5.1 Progress Payments § 5.1.1 Based upon Applications for Payment submitted to the Construction Manager by the Contractor, and Certificates for Payment issued by the Construction Manager and Architect, the Owner shall make progress payments on account of the Contract Sum, to the Contractor, as provided below and elsewhere in the Contract Documents. § 5.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows: § 5.1.3 Provided that an Application for Payment is received by the Construction Manager not later than the 23 day of a month, the Owner shall make payment of the amount certified to the Contractor not later than the last day of the following month. If an Application for Payment is received by the Construction Manager after the application date fixed above, payment of the amount certified shall be made by the Owner not later than 60 ( sixty ) days after the Construction Manager receives the Application for Payment. (Federal, state or local laws may require payment within a certain period of time.) § 5.1.4 Progress Payments Where the Contract Sum is Based on a Stipulated Sum § 5.1.4.1 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents. The schedule of values shall allocate the entire Contract Sum among the various portions of the Work. The schedule of values shall be prepared in such form, and supported by such data to substantiate its accuracy, as the Construction Manager and Architect may require. This schedule of values shall be used as a basis for reviewing the Contractor’s Applications for Payment. § 5.1.4.2 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. § 5.1.4.3 In accordance with AIA Document A232™–2019 as amended, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition, and subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: § 5.1.4.3.1 The amount of each progress payment shall first include: .1 That portion of the Contract Sum properly allocable to completed Work; .2 That portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction, or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing; and .3 That portion of Construction Change Directives that the Architect determines, in the Architect’s professional judgment, to be reasonably justified. § 5.1.4.3.2 The amount of each progress payment shall then be reduced by: .1 The aggregate of any amounts previously paid by the Owner; .2 The amount, if any, for Work that remains uncorrected and for which the Architect has previously withheld a Certificate for Payment as provided in Article 9 of AIA Document A232–2019; .3 Any amount for which the Contractor does not intend to pay a Subcontractor or material supplier, unless the Work has been performed by others the Contractor intends to pay; .4 For Work performed or defects discovered since the last payment application, any amount for which the Architect may withhold payment, or nullify a Certificate of Payment in whole or in part, as provided in Article 9 of AIA Document A232–2019; and .5 Retainage withheld pursuant to Section 5.1.7. 5.1.4.4 The progress payment amount determined in accordance with Section 5.1.4.3 shall be further modified under the following circumstances: .1 Add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to Ninety-Seven percent ( 97 %) of the Contract Sum, less such amounts as the Construction Manager recommends and the Architect determines for incomplete Work and unsettled claims; and Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 6 .2 Add, if final completion of the Work is thereafter materially delayed through no fault of the Contractor, any additional amounts payable in accordance with Section 9.10.3 of the General Conditions. (Paragraphs deleted) § 5.1.7 Retainage § 5.1.7.1 For each progress payment made prior to when the Work of this Contract is substantially complete, the Owner may withhold the following amount, as retainage, from the payment otherwise due: (Insert a percentage or amount to be withheld as retainage from each Application for Payment. The amount of retainage may be limited by governing law.) 3% § 5.1.7.1.1 The following items are not subject to retainage: (Insert any items not subject to the withholding of retainage, such as general conditions, insurance, etc.) § 5.1.7.2 Reduction or limitation of retainage, if any, shall be as follows: (If the retainage established in Section 5.1.7.1 is to be modified prior to when the entire Work of this Contract is substantially complete, including modifications for completion of portions of the Work as provided in Section 3.4.2, insert provisions for such modifications.) § 5.1.7.3 Except as set forth in this Section 5.1.7.3, when the Work of this Contract is complete and formally Finally Accepted by Owner, the Contractor may submit an Application for Payment that includes the retainage withheld from prior Applications for Payment pursuant to this Section 5.1.7. Payment of retainage to contractor will be made to Contractor after the expiration of 30 days from completion and final acceptance of the project by Owner, less any outstanding claims filed pursuant to Iowa Code Chapter 573. (Insert any other conditions for release of retainage when the Work of this Contract is substantially complete, or upon Substantial Completion of the Work of all Contractors on the Project or portions thereof.) § 5.2 Final Payment § 5.2.1 Final Payment Where the Contract Sum is Based on a Stipulated Sum § 5.2.1.1 Final payment, constituting the entire unpaid balance of the Contract Sum less retainage, shall be made by the Owner to the Contractor when .1 the Contractor has fully performed the Contract except for the Contractor’s responsibility to correct Work as provided in Article 12 of AIA Document A232–2019, and to satisfy other requirements, if any, which extend beyond final payment; and .2 a final Certificate for Payment or Project Certificate for Payment has been issued by the Architect. § 5.2.1.2 The Owner’s final payment to the Contractor shall be made no later than 30 days after the issuance of the final Certificate for Payment or Project Certificate for Payment and: Retainage will be held by Owner and will be paid to contractor 30 days after Final Acceptance of the Project by the Owner as provided in Iowa Code Chapter 573 and applicable Iowa Law. : (Paragraphs deleted) Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 7 ARTICLE 6 DISPUTE RESOLUTION § 6.1 Initial Decision Maker The Architect will serve as Initial Decision Maker pursuant to Article 15 of AIA Document A232–2019, unless the parties appoint below another individual, not a party to this Agreement, to serve as Initial Decision Maker. (If the parties mutually agree, insert the name, address and other contact information of the Initial Decision Maker, if other than the Architect.) § 6.2 Binding Dispute Resolution For any Claim subject to, but not resolved by, mediation pursuant to Article 15 of AIA Document A232–2019, the method of binding dispute resolution shall be as follows: (Check the appropriate box.) [ ]Arbitration pursuant to Article 15 of AIA Document A232–2019. [ X ]Litigation in a court of competent jurisdiction. [ ]Other: (Specify) If the Owner and Contractor do not select a method of binding dispute resolution, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, Claims will be resolved by litigation in a court of competent jurisdiction. ARTICLE 7 TERMINATION OR SUSPENSION § 7.1 Where the Contract Sum is a Stipulated Sum (Paragraphs deleted) § 7.1.1.1The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A232–2019 as amended. § 7.1.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A232–2019 as amended. (Paragraphs deleted) ARTICLE 8 MISCELLANEOUS PROVISIONS § 8.1 Where reference is made in this Agreement to a provision of AIA Document A232–2019 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. § 8.2 The Owner’s representative: (Name, address, email address, and other information) § 8.3 The Contractor’s representative: (Name, address, email address, and other information) Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 8 § 8.4 Neither the Owner’s nor the Contractor’s representative shall be changed without ten days’ prior notice to the other party. § 8.5 Insurance and Bonds § 8.5.1 The Owner and the Contractor shall purchase and maintain insurance as set forth in AIA Document A132™–2019, Standard Form of Agreement Between Owner and Contractor, Construction Manager as Adviser Edition, Exhibit A, Insurance and Bonds, and elsewhere in the Contract Documents. § 8.5.2 The Contractor shall provide bonds as set forth in Exhibit A, Insurance and Bonds, and elsewhere in the Contract Documents. § 8.6 Notice in electronic format, pursuant to Article 1 of AIA Document A232–2019, may be given in accordance with AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, if completed, or as otherwise set forth below: (If other than in accordance with AIA Document E203–2013, insert requirements for delivering notice in electronic format such as name, title, and email address of the recipient and whether and how the system will be required to generate a read receipt for the transmission.) Nothing herein shall be deemed to limit, waive or restrict any statutory (including applicable municipal ordinances) limitations, restrictions or requirements applicable to governmental entities. § 8.7 Relationship of the Parties Where the Contract is based on the Cost of the Work plus the Contractor’s Fee, with or without a Guaranteed Maximum Price, the Contractor accepts the relationship of trust and confidence established by this Agreement and covenants with the Owner to cooperate with the Architect and exercise the Contractor’s skill and judgment in furthering the interests of the Owner; to furnish efficient business administration and supervision; to furnish at all times an adequate supply of workers and materials; and to perform the Work in an expeditious and economical manner consistent with the Owner’s interests. The Owner agrees to furnish and approve, in a timely manner, information required by the Contractor and to make payments to the Contractor in accordance with the requirements of the Contract Documents. § 8.8 Other provisions: ARTICLE 9 ENUMERATION OF CONTRACT DOCUMENTS § 9.1 This Agreement is comprised of the following documents: .1 AIA Document A132™–2019, Standard Form of Agreement Between Owner and Contractor, Construction Manager as Adviser Edition .2 AIA Document A132™–2019, Exhibit A, Insurance and Bonds Exhibit .3 AIA Document A232™–2019, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition in the form provided with this contract. .4 AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, dated as indicated below: (Insert the date of the E203-2013 incorporated into this Agreement.) .5 Drawings Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 9 Number Title Date See Drawings attached hereto as Exhibit D. .6 Specifications Section Title Date Pages See Specifications attached hereto as E. .7 Addenda, if any: Number Date Pages 01 12.12.2025 63 Portions of Addenda relating to bidding or proposal requirements are not part of the Contract Documents unless the bidding or proposal requirements are also enumerated in this Article 9. .8 Other Exhibits: (Check all boxes that apply and include appropriate information identifying the exhibit where required.) [ ]AIA Document A132™–2019, Exhibit B, Determination of the Cost of the Work [ ]AIA Document E235™–2019, Sustainable Projects Exhibit, Construction Manager as Adviser Edition, dated as indicated below: (Insert the date of the E235-2019 incorporated into this Agreement.) n/a [ ]The Sustainability Plan: Title Date Pages [ ]Supplementary and other Conditions of the Contract: Document Title Date Pages See Scope of Work and Supplementary Conditions Attached as Exhibit C. .9 Other documents, if any, listed below: (List here any additional documents that are intended to form part of the Contract Documents. AIA Document A232–2019 provides that the advertisement or invitation to bid, Instructions to Bidders, sample forms, the Contractor’s bid or proposal, portions of Addenda relating to bidding or proposal requirements, and other information furnished by the Owner in anticipation of receiving bids or proposals, are not part of the Contract Documents unless enumerated in this Agreement. Any such documents should be listed here only if intended to be part of the Contract Documents.) n/a This Agreement is entered into as of the day and year first written above. OWNER (Signature)CONTRACTOR (Signature) Init. / AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 10 (Printed name and title)(Printed name and title) Additions and Deletions Report for AIA® Document A132® – 2019 This Additions and Deletions Report, as defined on page 1 of the associated document, reproduces below all text the author has added to the standard form AIA document in order to complete it, as well as any text the author may have added to or deleted from the original AIA text. Added text is shown underlined. Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AIA document. This Additions and Deletions Report and its associated document were generated simultaneously by AIA software at 10:58:07 ET on 01/15/2026. Additions and Deletions Report for AIA Document A132 – 2019. Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 1 PAGE 1 AGREEMENT made as of the 19 day of January in the year 2026 … City of Waukee Iowa 230 W Hickman Road Waukee, IA 50263 … PDM Glass 220 SE 6th Street, Suite 100 Des Moines, IA 50309 … Waukee Existing Fire/Police Building Renovation 1300 SE La Grant Parkway, Waukee, Iowa 50263 Renovation of the existing Police/Fire Building … Ryan Companies, US Inc. 111 E Grand Avenue, Suite 200 Des Moines, IA 50309 … OPN Architects 100 Court Avenue, #100 Des Moines, IA 50309 PAGE 2 EXHIBIT B DETERMINATION OF THE COST OF THE WORKSCHEDULE EXHIBIT C SCOPE OF WORK EXHIBIT D DRAWINGS EXHIBIT E SPECIFICATIONS … [ X ]Established as follows: Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 2 … Within five (5) days of notice to proceed from Construction Manager PAGE 3 See Exhibit B attached hereto. Contractor shall be responsible to Substantially and Finally Complete its Scope of Work within the schedule limitations set forth on Exhibit B hereto. Contractor’s Scope of Work is set forth on Exhibit C hereto. … Bid Package #01 Exterior Glass & Glazing December 14, 2026 … [ X ]Stipulated Sum, in accordance with Section 4.2 below … § 4.2.1 The Contract Sum shall be One hundred fifty-five thousand, one hundred seventy dollars and zero cents. ($ $155,170.00 ), subject to additions and deductions as provided in the Contract Documents. PAGE 4 § 4.3 Cost of the Work Plus Contractor’s Fee without a Guaranteed Maximum Price § 4.3.1 The Cost of the Work is as defined in Exhibit B, Determination of the Cost of the Work. § 4.3.2 The Contractor’s Fee: (State a lump sum, percentage of Cost of the Work or other provision for determining the Contractor’s Fee.) § 4.3.3 The method of adjustment of the Contractor’s Fee for changes in the Work: § 4.3.4 Limitations, if any, on a Subcontractor’s overhead and profit for increases in the cost of its portion of the Work: § 4.3.5 Rental rates for Contractor-owned equipment shall not exceed percent ( %) of the standard rental rate paid at the place of the Project. § 4.3.6 Unit prices, if any: (Identify the item and state the unit price and quantity limitations, if any, to which the unit price will be applicable.) Item Units and Limitations Price per Unit ($0.00) § 4.3.7 The Contractor shall prepare and submit to the Construction Manager, within 14 days of executing this Agreement, a written Control Estimate for the Owner’s review and approval. The Control Estimate shall include the items in Section B.1 of Exhibit B, Determination of the Cost of the Work. § 4.4 Cost of the Work Plus Contractor’s Fee with a Guaranteed Maximum Price § 4.4.1 The Cost of the Work is as defined in Exhibit B, Determination of the Cost of the Work. § 4.4.2 The Contractor’s Fee: (State a lump sum, percentage of Cost of the Work or other provision for determining the Contractor’s Fee.) Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 3 § 4.4.3 The method of adjustment of the Contractor’s Fee for changes in the Work: § 4.4.4 Limitations, if any, on a Subcontractor’s overhead and profit for increases in the cost of its portion of the Work: § 4.4.5 Rental rates for Contractor-owned equipment shall not exceed percent ( %) of the standard rental rate paid at the place of the Project. § 4.4.6 Unit Prices, if any: (Identify the item and state the unit price and quantity limitations, if any, to which the unit price will be applicable.) Item Units and Limitations Price per Unit ($0.00) § 4.4.7 Guaranteed Maximum Price § 4.4.7.1 The Contract Sum is guaranteed by the Contractor not to exceed ($ ), subject to additions and deductions by Change Order as provided in the Contract Documents. This maximum sum is referred to in the Contract Documents as the Guaranteed Maximum Price. Costs which would cause the Guaranteed Maximum Price to be exceeded shall be paid by the Contractor without reimbursement by the Owner. § 4.4.7.2 Alternates § 4.4.7.2.1 Alternates, if any, included in the Guaranteed Maximum Price: Item Price § 4.4.7.2.2 Subject to the conditions noted below, the following alternates may be accepted by the Owner following execution of this Agreement. Upon acceptance, the Owner shall issue a Modification to this Agreement. (Insert below each alternate and the conditions that must be met for the Owner to accept the alternate.) Item Price Conditions for Acceptance § 4.4.7.3 Allowances, if any, included in the Guaranteed Maximum Price: (Identify each allowance.) Item Price § 4.4.7.4 Assumptions, if any, upon which the Guaranteed Maximum Price is based: (Identify each assumption.) § 4.4.8 To the extent that the Contract Documents are anticipated to require further development, the Guaranteed Maximum Price includes the costs attributable to such further development consistent with the Contract Documents and reasonably inferable therefrom. Such further development does not include changes in scope, systems, kinds and quality of materials, finishes, or equipment, all of which, if required, shall be incorporated by Change Order. § 4.4.9 The Owner shall authorize preparation of revisions to the Contract Documents that incorporate the agreed-upon assumptions contained in Section 4.4.7.4. The Owner shall promptly furnish such revised Contract Documents to the Contractor. The Contractor shall notify the Owner and Architect of any inconsistencies between the agreed-upon assumptions contained in Section 4.4.7.4 and the revised Contract Documents. Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 4 … If Substantial Completion is not achieved by the date specified in the Contract Documents, then Construction Manager shall pay the Owner liquidated damages in the amount of one-thousand dollars ($1,000.00) per day for each day beginning on the first day after the date specified in the Contract Documents up to but not including the Substantial Completion Date. If Final Completion is not achieved by the date specified in the Contract Documents, then Construction Manager shall pay the Owner liquidated damages in the amount of one-thousand dollars ($1,000.00) per day for each day beginning on the first day after the date specified in the Contract Documents up to but not including the Final Completion Date. PAGE 5 § 5.1.3 Provided that an Application for Payment is received by the Construction Manager not later than the 23 day of a month, the Owner shall make payment of the amount certified to the Contractor not later than the last day of the following month. If an Application for Payment is received by the Construction Manager after the application date fixed above, payment of the amount certified shall be made by the Owner not later than 60 ( sixty ) days after the Construction Manager receives the Application for Payment. … § 5.1.4.3 In accordance with AIA Document A232™–2019, A232™–2019 as amended, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition, and subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: … 5.1.4.4 The progress payment amount determined in accordance with Section 5.1.4.3 shall be further modified under the following circumstances: .1 Add, upon Substantial Completion of the Work, a sum sufficient to increase the total payments to Ninety-Seven percent ( 97 %) of the Contract Sum, less such amounts as the Construction Manager recommends and the Architect determines for incomplete Work and unsettled claims; and .2 Add, if final completion of the Work is thereafter materially delayed through no fault of the Contractor, any additional amounts payable in accordance with Section 9.10.3 of the General Conditions. § 5.1.5 Progress Payments Where the Contract Sum is Based on the Cost of the Work without a Guaranteed Maximum Price § 5.1.5.1 With each Application for Payment, the Contractor shall submit the cost control information required in Exhibit B, Determination of the Cost of the Work, along with payrolls, petty cash accounts, receipted invoices, or invoices with check vouchers attached, and any other evidence required by the Owner, Construction Manager or Architect to demonstrate that payments already made by the Contractor on account of the Cost of the Work equal or exceed progress payments already received by the Contractor, plus payrolls for the period covered by the present Application for Payment, less that portion of the payments attributable to the Contractor’s Fee. § 5.1.5.2 Applications for Payment shall show the Cost of the Work actually incurred by the Contractor through the end of the period covered by the Application for Payment and for which the Contractor has made or intends to make actual payment prior to the next Application for Payment. § 5.1.5.3 In accordance with AIA Document A232-2019 and subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: § 5.1.5.3.1 The amount of each progress payment shall first include: .1 The Cost of the Work as described in Exhibit B, Determination of the Cost of the Work; .2 That portion of Construction Change Directives that the Architect determines, in the Architect’s professional judgment, to be reasonably justified; and Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 5 .3 The Contractor’s Fee computed upon the Cost of the Work described in the preceding Section 5.1.5.3.1.1 at the rate stated in Section 4.3.2; or if the Contractor’s Fee is stated as a fixed sum in Section 4.3.2 an amount which bears the same ratio to that fixed-sum Fee as the Cost of the Work included in Section 5.1.5.3.1.1 bears to a reasonable estimate of the probable Cost of the Work upon its completion. § 5.1.5.3.2 The amount of each progress payment shall then be reduced by: .1 The aggregate of any amounts previously paid by the Owner; .2 The amount, if any, for Work that remains uncorrected and for which the Architect has previously withheld a Certificate for Payment as provided in Article 9 of AIA Document A232–2019; .3 Any amount for which the Contractor does not intend to pay a Subcontractor or material supplier, unless the Work has been performed by others the Contractor intends to pay; .4 For Work performed or defects discovered since the last payment application, any amount for which the Architect may withhold payment, or nullify a Certificate of Payment in whole or in part, as provided in Article 9 of AIA Document A232–2019; .5 The shortfall, if any, indicated by the Contractor in the documentation required by Section 5.1.5.1 to substantiate prior Applications for Payment, or resulting from errors subsequently discovered by the Owner’s auditors in such documentation; and .6 Retainage withheld pursuant to Section 5.1.7. § 5.1.5.4 The Owner, Construction Manager and Contractor shall agree upon a mutually acceptable procedure for review and approval of payments to Subcontractors and the percentage of retainage held on Subcontracts, and the Contractor shall execute subcontracts in accordance with those agreements. § 5.1.5.5 In taking action on the Contractor’s Applications for Payment, the Construction Manager and Architect shall be entitled to rely on the accuracy and completeness of the information furnished by the Contractor, and such action shall not be deemed to be a representation that (1) the Construction Manager and Architect have made a detailed examination, audit or arithmetic verification of the documentation submitted in accordance with Article 5 or other supporting data; (2) that the Construction Manager and Architect have made exhaustive or continuous on-site inspections; or (3) that the Construction Manager and Architect have made examinations to ascertain how or for what purposes the Contractor has used amounts previously paid on account of the Contract. Such examinations, audits and verifications, if required by the Owner, will be performed by the Owner’s auditors acting in the sole interest of the Owner. § 5.1.5.6 Except with the Owner’s prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. § 5.1.5.7 If final completion of the Work is materially delayed through no fault of the Contractor, then the Owner shall pay the Contractor any additional amounts in accordance with Article 9 of AIA Document A232-2019. § 5.1.6 Progress Payments Where the Contract Sum is Based on the Cost of the Work with a Guaranteed Maximum Price § 5.1.6.1 With each Application for Payment, the Contractor shall submit payrolls, petty cash accounts, receipted invoices or invoices with check vouchers attached, and any other evidence required by the Owner, Construction Manager or Architect to demonstrate that payments already made by the Contractor on account of the Cost of the Work equal or exceed progress payments already received by the Contractor plus payrolls for the period covered by the present Application for Payment, less that portion of the progress payments attributable to the Contractor’s Fee. § 5.1.6.2 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contractor in accordance with the Contract Documents. The schedule of values shall allocate the entire Guaranteed Maximum Price among: (1) the various portions of the Work; (2) any contingency for costs that are included in the Guaranteed Maximum Price but not otherwise allocated to another line item or included in a Change Order; and (3) the Contractor’s Fee. § 5.1.6.2.1 The schedule of values shall be prepared in such form, and supported by such data to substantiate its accuracy, as the Construction Manager and Architect may require. This schedule of values shall be used as a basis for reviewing the Contractor’s Applications for Payment. Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 6 § 5.1.6.2.2 The allocation of the Guaranteed Maximum Price under this Section 5.1.6.2 shall not constitute a separate guaranteed maximum price for the Cost of the Work of each individual line item in the schedule of values. § 5.1.6.2.3 When the Contractor allocates costs from a contingency to another line item in the schedule of values, the Contractor shall submit supporting documentation to the Architect and Construction Manager. § 5.1.6.3 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. The percentage of completion shall be the lesser of (1) the percentage of that portion of the Work which has actually been completed; or (2) the percentage obtained by dividing (a) the expense that has actually been incurred by the Contractor on account of that portion of the Work and for which the Contractor has made payment or intends to make payment prior to the next Application for Payment by (b) the share of the Guaranteed Maximum Price allocated to that portion of the Work in the schedule of values. § 5.1.6.4 In accordance with AIA Document A232-2019, and subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: § 5.1.6.4.1 The amount of each progress payment shall first include: .1 That portion of the Guaranteed Maximum Price properly allocable to completed Work as determined by multiplying the percentage of completion of each portion of the Work by the share of the Guaranteed Maximum Price allocated to that portion of the Work in the most recent schedule of values; .2 That portion of the Guaranteed Maximum Price properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction or, if approved in writing in advance by the Owner, suitably stored off the site at a location agreed upon in writing; .3 That portion of Construction Change Directives that the Architect determines, in the Architect’s professional judgment, to be reasonably justified; and .4 The Contractor’s Fee, computed upon the Cost of the Work described in the preceding Sections 5.1.6.4.1.1 and 5.1.6.4.1.2 at the rate stated in Section 4.4.2 or, if the Contractor’s Fee is stated as a fixed sum in that Section, an amount that bears the same ratio to that fixed-sum fee as the Cost of the Work included in Sections 5.1.6.4.1.1 and 5.1.6.4.1.2 bears to a reasonable estimate of the probable Cost of the Work upon its completion. § 5.1.6.4.2 The amount of each progress payment shall then be reduced by: .1 The aggregate of any amounts previously paid by the Owner; .2 The amount, if any, for Work that remains uncorrected and for which the Architect has previously withheld a Certificate for Payment as provided in Article 9 of AIA Document A232–2019; .3 Any amount for which the Contractor does not intend to pay a Subcontractor or material supplier, unless the Work has been performed by others the Contractor intends to pay; .4 For Work performed or defects discovered since the last payment application, any amount for which the Architect may withhold payment, or nullify a Certificate of Payment in whole or in part, as provided in Article 9 of AIA Document A232–2019; .5 The shortfall, if any, indicated by the Contractor in the documentation required by Section 5.1.6.1 to substantiate prior Applications for Payment, or resulting from errors subsequently discovered by the Owner’s auditors in such documentation; and .6 Retainage withheld pursuant to Section 5.1.7. § 5.1.6.5 The Owner and the Contractor shall agree upon a mutually acceptable procedure for review and approval of payments to Subcontractors and the percentage of retainage held on Subcontracts, and the Contractor shall execute subcontracts in accordance with those agreements. § 5.1.6.6 In taking action on the Contractor’s Applications for Payment, the Construction Manager and Architect shall be entitled to rely on the accuracy and completeness of the information furnished by the Contractor and such action shall not be deemed to be a representation that (1) the Construction Manager or Architect have made a detailed examination, audit, or arithmetic verification of the documentation submitted in accordance with Section 5.1.6.1 or other supporting data; (2) that the Construction Manager or Architect have made exhaustive or continuous on-site inspections; or (3) that the Construction Manager or Architect have made examinations to ascertain how or for what Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 7 purposes the Contractor has used amounts previously paid on account of the Contract. Such examinations, audits, and verifications, if required by the Owner, will be performed by the Owner’s auditors acting in the sole interest of the Owner. § 5.1.6.7 Except with the Owner’s prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. § 5.1.6.8 If final completion of the Work is materially delayed through no fault of the Contractor, then the Owner shall pay the Contractor any additional amounts in accordance with Article 9 of AIA Document A232-2019. PAGE 6 3% … § 5.1.7.3 Except as set forth in this Section 5.1.7.3, when the Work of this Contract is substantially complete, complete and formally Finally Accepted by Owner, the Contractor may submit an Application for Payment that includes the retainage withheld from prior Applications for Payment pursuant to this Section 5.1.7. The Application for Payment submitted when the Work of this Contract is substantially complete shall not include retainage as follows:Payment of retainage to contractor will be made to Contractor after the expiration of 30 days from completion and final acceptance of the project by Owner, less any outstanding claims filed pursuant to Iowa Code Chapter 573. … § 5.2.1.1 Final payment, constituting the entire unpaid balance of the Contract Sum, Sum less retainage, shall be made by the Owner to the Contractor when … § 5.2.1.2 The Owner’s final payment to the Contractor shall be made no later than 30 days after the issuance of the final Certificate for Payment or Project Certificate for Payment, or as follows:Payment and: Retainage will be held by Owner and will be paid to contractor 30 days after Final Acceptance of the Project by the Owner as provided in Iowa Code Chapter 573 and applicable Iowa Law. : … § 5.2.2 Final Payment Where the Contract Sum is Based on the Cost of the Work with or without a Guaranteed Maximum Price § 5.2.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when .1 the Contractor has fully performed the Contract except for the Contractor’s responsibility to correct Work as provided in Article 12 of AIA Document A232–2019, and to satisfy other requirements, if any, which extend beyond final payment; .2 the Contractor has submitted a final accounting for the Cost of the Work, pursuant to Exhibit B, Determination of the Cost of the Work and a final Application for Payment; and .3 a final Certificate for Payment or Project Certificate for Payment has been issued by the Architect in accordance with Exhibit B, Determination of the Cost of the Work. § 5.2.2.2 The Owner’s final payment to the Contractor shall be made no later than 30 days after the issuance of the final Certificate for Payment or Project Certificate for Payment, or as follows: Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 8 § 5.3 Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. (Insert rate of interest agreed upon, if any.) % PAGE 7 [ X ]Litigation in a court of competent jurisdiction. … § 7.1.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A232–2019. § 7.1.1.1 If the Contract is terminated for the Owner’s convenience in accordance with Article 14 of AIA Document A232–2019, then the Owner shall pay the Contractor a termination fee as follows: (Insert the amount of, or method for determining, the fee, if any, payable to the Contractor following a termination for the Owner’s convenience.) § 7.1.1.1The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A232–2019 as amended. § 7.1.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A232–2019.A232–2019 as amended. § 7.2 Where the Contract Sum is Based on the Cost of the Work with or without a Guaranteed Maximum Price § 7.2.1 Termination § 7.2.1.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A232–2019. § 7.2.1.2 Termination by the Owner for Cause § 7.2.1.2.1 If the Owner terminates the Contract for cause as provided in Article 14 of AIA Document A232–2019, the Owner shall then only pay the Contractor an amount as follows: .1 Take the Cost of the Work incurred by the Contractor to the date of termination; .2 Add the Contractor’s Fee, computed upon the Cost of the Work to the date of termination at the rate stated in Section 4.3.2 or 4.4.2, as applicable, or, if the Contractor’s Fee is stated as a fixed sum in that Section, an amount that bears the same ratio to that fixed-sum Fee as the Cost of the Work at the time of termination bears to a reasonable estimate of the probable Cost of the Work upon its completion; .3 Subtract the aggregate of previous payments made by the Owner; and .4 Subtract the costs and damages incurred, or to be incurred, by the Owner under Article 14 of AIA Document A232–2019. § 7.2.1.2.2 When the Contract Sum is based on the Cost of the Work with a Guaranteed Maximum Price, if the Owner terminates the Contract for cause as provided in Article 14 of AIA Document A232-2019, the amount, if any, to be paid to the Contractor under Article 14 of AIA Document A232-2019 shall not cause the Guaranteed Maximum Price to be exceeded, nor shall it exceed the amount calculated in Section 7.2.1.2.1. § 7.2.1.2.3 The Owner shall also pay the Contractor fair compensation, either by purchase or rental at the election of the Owner, for any equipment owned by the Contractor that the Owner elects to retain and that is not otherwise included in the Cost of the Work under Section 7.2.1.2.1.1. To the extent that the Owner elects to take legal assignment Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 9 of subcontracts and purchase orders (including rental agreements), the Contractor shall, as a condition of receiving the payments referred to in this Article 7, execute and deliver all such papers and take all such steps, including the legal assignment of such subcontracts and other contractual rights of the Contractor, as the Owner may require for the purpose of fully vesting in the Owner the rights and benefits of the Contractor under such subcontracts or purchase orders. All Subcontracts, purchase orders and rental agreements entered into by the Contractor will contain provisions allowing for assignment to the Owner as described above. § 7.2.1.3 Termination by the Owner for Convenience If the Owner terminates the Contract for convenience in accordance with Article 14 of AIA Document A232–2019, then the Owner shall pay the Contractor a termination fee as follows: (Insert the amount of or method for determining the fee, if any, payable to the Contractor following a termination for the Owner’s convenience.) § 7.3 Suspension The Work may be suspended by the Owner as provided in Article 14 of AIA Document A232–2019; in such case, the Contract Sum and Contract Time shall be increased as provided in Article 14 of AIA Document A232–2019, except that the term "profit" shall be understood to mean the Contractor’s Fee as described in Section 4.3.2 or 4.4.2, as applicable, of this Agreement. PAGE 8 § 8.5.2 The Contractor shall provide bonds as set forth in AIA Document A132™–2019, Exhibit A, Insurance and Bonds, and elsewhere in the Contract Documents. § 8.6 Notice in electronic format, pursuant to Article 1 of AIA Document A232–2019, may be given in accordance with a building information modeling exhibit, AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, if completed, or as otherwise set forth below: (If other than in accordance with a building information modeling exhibit, AIA Document E203–2013, insert requirements for delivering notice in electronic format such as name, title, and email address of the recipient and whether and how the system will be required to generate a read receipt for the transmission.) Nothing herein shall be deemed to limit, waive or restrict any statutory (including applicable municipal ordinances) limitations, restrictions or requirements applicable to governmental entities. … .3 AIA Document A232™–2019, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition in the form provided with this contract. .4 Building Information Modeling Exhibit, if completed:AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, dated as indicated below: (Insert the date of the E203-2013 incorporated into this Agreement.) PAGE 9 See Drawings attached hereto as Exhibit D. … See Specifications attached hereto as E. … 01 12.12.2025 63 Additions and Deletions Report for AIA Document A132 –2019.Copyright © 1975, 1980, 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 10 … n/a … See Scope of Work and Supplementary Conditions Attached as Exhibit C. … n/a AIA Document D401 – 2003. Copyright © 1992 and 2003. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:07 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1315588911) 1 Certification of Document’s Authenticity AIA® Document D401™ – 2003 I, Kerry Nelsen, hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 10:58:07 ET on 01/15/2026 under Order No. 4104251064 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA® Document A132™ – 2019, Standard Form of Agreement Between Owner and Contractor, Construction Manager as Adviser Edition, other than those additions and deletions shown in the associated Additions and Deletions Report. _____________________________________________________________ (Signed) _____________________________________________________________ (Title) _____________________________________________________________ (Dated) Document A232® – 2019 General Conditions of the Contract for Construction, Construction Manager as Adviser Edition Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 1 ADDITIONS AND DELETIONS: The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. This document is intended to be used in conjunction with AIA Documents A132™–2019, Standard Form of Agreement Between Owner and Contractor, Construction Manager as Adviser Edition; B132™–2019, Standard Form of Agreement Between Owner and Architect, Construction Manager as Adviser Edition; and C132™–2019, Standard Form of Agreement Between Owner and Construction Manager as Adviser. for the following PROJECT: (Name, and location or address) Waukee Existing Fire/Police Building Renovation 1300 SE La Grant Parkway, Waukee, Iowa 50263 THE CONSTRUCTION MANAGER: (Name, legal status, and address) Ryan Companies, US Inc. 111 E Grand Avenue, Suite 200 Des Moines, IA 50309 THE OWNER: (Name, legal status, and address) City of Waukee Iowa 230 W Hickman Road Waukee, IA 50263 THE ARCHITECT: (Name, legal status, and address) OPN Architects 100 Court Avenue, #100 Des Moines, IA 50309 Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 2 TABLE OF ARTICLES 1 GENERAL PROVISIONS 2 OWNER 3 CONTRACTOR 4 ARCHITECT AND CONSTRUCTION MANAGER 5 SUBCONTRACTORS 6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS 7 CHANGES IN THE WORK 8 TIME 9 PAYMENTS AND COMPLETION 10 PROTECTION OF PERSONS AND PROPERTY 11 INSURANCE AND BONDS 12 UNCOVERING AND CORRECTION OF WORK 13 MISCELLANEOUS PROVISIONS 14 TERMINATION OR SUSPENSION OF THE CONTRACT 15 CLAIMS AND DISPUTES Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 3 ARTICLE 1 GENERAL PROVISIONS § 1.1 Basic Definitions § 1.1.1 The Contract Documents. The Contract Documents are enumerated in the Agreement between the Owner and Contractor (hereinafter the Agreement) and consist of the Agreement, Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to execution of the Contract, other documents listed in the Agreement, and Modifications issued after execution of the Contract. A Modification is (1) a written amendment to the Contract signed by both parties, (2) a Change Order, (3) a Construction Change Directive, or (4) a written order for a minor change in the Work issued by the Architect. Unless specifically enumerated in the Agreement, the Contract Documents do not include the advertisement or invitation to bid, Instructions to Bidders, sample forms, other information furnished by the Owner in anticipation of receiving bids or proposals, the Contractor’s bid or proposal, or portions of addenda relating to bidding or proposal requirements. § 1.1.2 The Contract. The Contract Documents form the Contract for Construction. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations, or agreements, either written or oral. The Contract may be amended or modified only by a Modification. The Contract Documents shall not be construed to create a contractual relationship of any kind (1) between the Contractor and the Architect or the Architect’s consultants, (2) between the Owner and the Construction Manager or the Construction Manager’s consultants, (3) between the Owner and the Architect or the Architect’s consultants, (4) between the Contractor and the Construction Manager or the Construction Manager’s consultants, (5) between the Owner and a Subcontractor or Sub-subcontractor (6) between the Construction Manager and the Architect, or (7) between any persons or entities other than the Owner and Contractor. The Construction Manager and Architect shall, however, be entitled to performance and enforcement of obligations under the Contract intended to facilitate performance of their duties. § 1.1.3 The Work. The term "Work" means the construction and services required by the Contract Documents, whether completed or partially completed, and includes all other labor, materials, equipment, and services provided or to be provided by the Contractor to fulfill the Contractor’s obligations. The Work may constitute the whole or a part of the Project. § 1.1.4 The Project. The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part and which may include construction by other Contractors, and by the Owner’s own forces and Separate Contractors. § 1.1.5 Contractors. Contractors are persons or entities, other than the Contractor or Separate Contractors, who perform Work under contracts with the Owner that are administered by the Architect and Construction Manager. § 1.1.6 Separate Contractors. Separate Contractors are persons or entities who perform construction under separate contracts with the Owner not administered by the Architect and Construction Manager. § 1.1.7 The Drawings. The Drawings are the graphic and pictorial portions of the Contract Documents showing the design, location and dimensions of the Work, generally including plans, elevations, sections, details, schedules, and diagrams. § 1.1.8 The Specifications. The Specifications are that portion of the Contract Documents consisting of the written requirements for materials, equipment, systems, standards and workmanship for the Work, and performance of related services. § 1.1.9 Instruments of Service. Instruments of Service are representations, in any medium of expression now known or later developed, of the tangible and intangible creative work performed by the Architect and the Architect’s consultants under their respective professional services agreements. Instruments of Service may include, without limitation, studies, surveys, models, sketches, drawings, specifications, and other similar materials. § 1.1.10 Initial Decision Maker. The Initial Decision Maker is the person identified in the Agreement to render initial decisions on Claims in accordance with Section 15.2. The Initial Decision Maker shall not show partiality to the Owner or Contractor and shall not be liable for results of interpretations or decisions rendered in good faith. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 4 § 1.2 Correlation and Intent of the Contract Documents § 1.2.1 The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by the Contractor and to require the furnishing of the highest quality equipment, material, and workmanship, and best accepted construction practices The Contract Documents are complementary, and what is required by one shall be as binding as if required by all; performance by the Contractor shall be required only to the extent consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the indicated results. § 1.2.1.1 The invalidity of any provision of the Contract Documents shall not invalidate the Contract or its remaining provisions. If it is determined that any provision of the Contract Documents violates any law, or is otherwise invalid or unenforceable, then that provision shall be revised to the extent necessary to make that provision legal and enforceable. In such case the Contract Documents shall be construed, to the fullest extent permitted by law, to give effect to the parties’ intentions and purposes in executing the Contract. § 1.2.2 Organization of the Specifications into divisions, sections and articles, and arrangement of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in establishing the extent of Work to be performed by any trade. § 1.2.3 Unless otherwise stated in the Contract Documents, words that have well-known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings. § 1.3 Capitalization Terms capitalized in these General Conditions include those that are (1) specifically defined, (2) the titles of numbered articles, or (3) the titles of other documents published by the American Institute of Architects. § 1.4 Interpretation In the interest of brevity the Contract Documents frequently omit modifying words such as "all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is not intended to affect the interpretation of either statement. § 1.5 Ownership and Use of Drawings, Specifications, and Other Instruments of Service § 1.5.1 Without waiving or otherwise altering the license granted in the contracts between Owner and Architect and Architect’s consultants, the Architect and the Architect’s consultants shall be deemed the authors and owners of their respective Instruments of Service, including the Drawings and Specifications, and retain all common law, statutory, and other reserved rights in their Instruments of Service, including copyrights. The Contractor, Subcontractors, sub-subcontractors, and suppliers shall not own or claim a copyright in the Instruments of Service. Submittal or distribution to meet official regulatory requirements or for other purposes in connection with the Project is not to be construed as publication in derogation of the Architect’s or Architect’s consultants’ reserved rights. § 1.5.2 Without waiving or otherwise altering the license granted in the contracts between Owner and Architect and Architect’s consultants, the Contractor, Subcontractors, Sub-subcontractors, and suppliers are authorized to use and reproduce the Instruments of Service provided to them, subject to any protocols established pursuant to Sections 1.7 and 1.8, solely and exclusively for execution of the Work. All copies made under this authorization shall bear the copyright notice, if any, shown on the Instruments of Service. The Contractor, Subcontractors, Sub-subcontractors, and suppliers may not use the Instruments of Service on other projects or for additions to the Project outside the scope of the Work without the specific written consent of the Owner, Architect, and the Architect’s consultants. § 1.6 Notice § 1.6.1 Except as otherwise provided in Section 1.6.2, where the Contract Documents require one party to notify or give notice to the other party, such notice shall be provided in writing to the designated representative of the party to whom the notice is addressed and shall be deemed to have been duly served if delivered in person, by mail, by courier, or by electronic transmission if a method for electronic transmission is set forth in the Agreement. § 1.6.2 Notice of Claims as provided in Section 15.1.3 shall be provided in writing and shall be deemed to have been duly served only if delivered to the designated representative of the party to whom the notice is addressed by certified or registered mail, or by courier providing proof of delivery. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 5 § 1.7 Digital Data Use and Transmission The parties shall agree upon protocols governing the transmission and use of Instruments of Service or any other information or documentation in digital form. The parties will use AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, to establish the protocols for the development, use, transmission, and exchange of digital data. § 1.8 Building Information Models Use and Reliance Any use of, or reliance on, all or a portion of a building information model without agreement to protocols governing the use of, and reliance on, the information contained in the model and without having those protocols set forth in AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, and the requisite AIA Document G202™–2013, Project Building Information Modeling Protocol Form, shall be at the using or relying party’s sole risk and without liability to the other party and its contractors or consultants, the authors of, or contributors to, the building information model, and each of their agents and employees. ARTICLE 2 OWNER § 2.1 General § 2.1.1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The Owner shall designate in writing a representative who shall have express authority to bind the Owner with respect to all matters requiring the Owner’s approval or authorization. Except as otherwise provided in Section 4.2.1, the Construction Manager and the Architect do not have such authority. The term "Owner" means the Owner or the Owner’s authorized representative. (Paragraphs deleted) § 2.3 Information and Services Required of the Owner § 2.3.1 Except for permits and fees that are the responsibility of the Contractor under the Contract Documents, including those required under Section 3.7.1, the Owner shall secure and pay for necessary approvals, easements, assessments and charges required for construction, use or occupancy of permanent structures or for permanent changes in existing facilities. § 2.3.2 The Owner shall retain an architect lawfully licensed to practice architecture, or an entity lawfully practicing architecture, in the jurisdiction where the Project is located. That person or entity is identified as the Architect in the Agreement and is referred to throughout the Contract Documents as if singular in number. § 2.3.3 The Owner shall retain a construction manager adviser lawfully practicing construction management in the jurisdiction where the Project is located. That person or entity is identified as the Construction Manager in the Agreement and is referred to throughout the Contract Documents as if singular in number. § 2.3.4 If the employment of the Construction Manager or Architect terminates, the Owner shall employ a successor construction manager or architect to whom the Contractor has no reasonable objection and whose status under the Contract Documents shall be that of the Construction Manager or Architect, respectively. § 2.3.5 The Owner shall furnish surveys describing physical characteristics, legal limitations and utility locations for the site of the Project, and a legal description of the site. The Contractor shall be entitled to rely on the accuracy of information furnished by the Owner but shall exercise proper precautions relating to the safe performance of the Work. § 2.3.6 The Owner shall furnish information or services required of the Owner by the Contract Documents with reasonable promptness. The Owner shall also furnish any other information or services under the Owner’s control and relevant to the Contractor’s performance of the Work with reasonable promptness after receiving the Contractor’s written request for such information or services. § 2.3.7 Unless otherwise provided in the Contract Documents, the Owner shall furnish to the Contractor one copy of the Contract Documents for purposes of making reproductions pursuant to Section 1.5.2. § 2.3.8 The Owner shall forward all communications to the Contractor through the Construction Manager. Other communication shall be made as set forth in Section 4.2.6. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 6 § 2.4 Owner’s Right to Stop the Work If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Section 6.1.3. § 2.5 Owner’s Right to Carry Out the Work If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten-day period after receipt of notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such default or neglect. Such action by the Owner and amounts charged to the Contractor are both subject to review by the Construction Manager and prior approval of the Architect, and the Construction Manager or Architect may, pursuant to Section 9.5.1, withhold or nullify a Certificate for Payment in whole or in part, to the extent reasonably necessary to reimburse the Owner for the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Construction Manager’s and Architect’s and their respective consultants’ additional services made necessary by such default, neglect, or failure. If current and future payments are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. ARTICLE 3 CONTRACTOR § 3.1 General § 3.1.1 The Contractor is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The Contractor shall be lawfully licensed, if required in the jurisdiction where the Project is located. The Contractor shall designate in writing a representative who shall have express authority to bind the Contractor with respect to all matters under this Contract. The term "Contractor" means the Contractor or the Contractor’s authorized representative. § 3.1.2 The Contractor shall perform the Work in accordance with industry standard and in a excellent and workmanlike manner complete the work and everything properly incidental thereto as stated in the Project Manual and Drawings or reasonably implied therefrom and otherwise in accordance with Contract Documents. In no case shall the Contractor proceed with any portion of the Work in any uncertainty. § 3.1.3 The Contractor shall not be relieved of its obligations to perform the Work in accordance with the Contract Documents either by activities or duties of the Construction Manager or Architect in their administration of the Contract, or by tests, inspections or approvals required or performed by persons or entities other than the Contractor. § 3.2 Review of Contract Documents and Field Conditions by Contractor § 3.2.1 Execution of the Contract by the Contractor is a representation that the Contractor has visited the Project site and has and carefully examined the Site, the Contract Documents, and is fully informed concerning the requirements of the Contract, the physical conditions to be encountered, the quantity of the Work, as well as materials and equipment to be furnished, become generally familiar with local conditions under which the Work is to be performed, and correlated personal observations with requirements of the Contract Documents. The Contractor also represents that all Contract Documents for the Project have been examined; including those intended for work of trades not normally performed by the Contractor’s own forces, and that it has become thoroughly familiar with all conditions which may pertain to or affect the Work under the Contract. § 3.2.2 Because the Contract Documents are complementary, the Contractor shall, before starting each portion of the Work, carefully study and compare the various Contract Documents relative to that portion of the Work, as well as the information furnished by the Owner pursuant to Section 2.3.5, shall take field measurements of any existing conditions related to that portion of the Work, and shall observe any conditions at the site affecting it. These obligations are for the purpose of facilitating coordination and construction by the Contractor and are not for the purpose of discovering errors, omissions, or inconsistencies in the Contract Documents; however, the Contractor shall promptly report to the Construction Manager and Architect any errors, inconsistencies or omissions discovered by or made known to the Contractor as a request for information submitted to the Construction Manager in such form as the Construction Manager and Architect may require. It is recognized that the Contractor’s review is made in the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 7 Contractor’s capacity as a contractor and not as a licensed design professional, unless otherwise specifically provided in the Contract Documents. § 3.2.3 If the Contractor believes that any portions of the Contract Documents do not comply with applicable laws, statutes, ordinances, building codes, and rules and regulations, or any orders by code enforcement officials or the Owner or its designees acting in the capacity of building code inspectors, the Contractor shall promptly report to the Construction Manager and Architect any nonconformity discovered by or made known to the Contractor as a request for information submitted to Construction Manager in such form as the Construction Manager and Architect may require before proceeding with the affected Work. § 3.2.4 If the Contractor fails to perform the obligations of Sections 3.2.2 or 3.2.3, the Contractor shall pay such costs and damages to the Owner, subject to section 15.1.7, as would have been avoided if the Contractor had performed such obligations. If the Contractor performs those obligations, the Contractor shall not be liable to the Owner or Architect for damages resulting from errors, inconsistencies or omissions in the Contract Documents, for differences between field measurements or conditions and the Contract Documents, or for nonconformities of the Contract Documents to applicable laws, statutes, ordinances, codes, rules and regulations, and lawful orders of public authorities. § 3.3 Supervision and Construction Procedures § 3.3.1 The Contractor shall supervise and direct the Work, using the Contractor’s best skill and attention. The Contractor shall be solely responsible for, and have control over, construction means, methods, techniques, sequences, and procedures, and for coordinating all portions of the Work under the Contract. If the Contract Documents give specific instructions concerning construction means, methods, techniques, sequences, or procedures, the Contractor shall evaluate the jobsite safety thereof and shall be solely responsible for the jobsite safety of such means, methods, techniques, sequences, or procedures. If the Contractor determines that such means, methods, techniques, sequences or procedures may not be safe, the Contractor shall give timely notice to the Owner, the Construction Manager, and the Architect, and shall propose alternative means, methods, techniques, sequences, or procedures. The Architect shall evaluate the proposed alternative solely for conformance with the design intent for the completed construction. The Construction Manager shall review the proposed alternative for sequencing, constructability, and coordination impacts on the other Contractors. Unless the Architect or the Construction Manager objects to the Contractor’s proposed alternative, the Contractor shall perform the Work using its alternative means, methods, techniques, sequences, or procedures. § 3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the Contractor’s employees, Subcontractors and their agents and employees, and other persons or entities performing portions of the Work for, or on behalf of, the Contractor or any of its Subcontractors. § 3.3.3 The Contractor shall be responsible for inspection of portions of the Project already performed to determine that such portions are in proper condition to receive subsequent Work. § 3.4 Labor and Materials § 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. § 3.4.2 Except in the case of minor changes in the Work approved by the Architect in accordance with Section 3.12.8 or ordered by the Architect in accordance with Section 7.4, the Contractor may make substitutions only with the consent of the Owner, after evaluation by the Architect, in consultation with the Construction Manager, and in accordance with a Change Order or Construction Change Directive. § 3.4.3 The Contractor shall enforce strict discipline and good order among the Contractor’s employees and other persons carrying out the Work. The Contractor shall not permit employment of unfit persons or persons not properly skilled in tasks assigned to them. § 3.5 Warranty § 3.5.1 The Contractor warrants to the Owner, Construction Manager, and Architect that materials and equipment furnished under the Contract will be of good quality and new unless the Contract Documents require or permit Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 8 otherwise. The Contractor further warrants that the Work will conform to the requirements of the Contract Documents and will be completed in a good and workman like manner and free from defects,. Work, materials, or equipment not conforming to these requirements may be considered defective. If required by the Construction Manager or Architect, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. § 3.5.2 All material, equipment, or other special warranties required by the Contract Documents shall be issued in the name of the Owner, or shall be transferable to the Owner, and shall commence in accordance with Section 9.8.4. § 3.6 Taxes The Contractor shall pay required consumer, use and similar taxes for the Work or portions thereof provided by the Contractor that are legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to go into effect. However, The Owner is a designated exempt entity and will complete an online application to register this Contract with the Iowa Department of Revenue and Finance. The Owner will distribute Tax Exemption Certificates and Authorization Letters to the Contractor and all Subcontractors who have been identified by Contractor. Refer to Iowa Department of Revenue and Finance publications available at http://www.state.ia.us/tax/business/Contr-ExEnt-Index.html. Contractor shall be responsible for informing themselves of tax laws, requirements, regulations, and interpretations as they apply to this Project. § 3.7 Permits, Fees, Notices, and Compliance with Laws § 3.7.1 Unless otherwise provided in the Contract Documents, the Owner, assisted by the Construction Manager, shall secure and pay for the building permit. The Contractor shall secure and pay for other permits, fees, licenses, and inspections by government agencies necessary for proper execution and completion of the Work that are customarily secured after execution of the Contract and legally required at the time bids are received or negotiations concluded. § 3.7.2 The Contractor shall comply with and give notices required by applicable laws, statutes, ordinances, codes, rules and regulations, and lawful orders of public authorities applicable to performance of the Work. § 3.7.3 If the Contractor performs Work knowing it to be contrary to applicable laws, statutes, ordinances, codes, rules and regulations, or lawful orders of public authorities, the Contractor shall assume appropriate responsibility for such Work and shall bear the costs attributable to correction. § 3.7.4 Concealed or Unknown Conditions. If the Contractor encounters conditions at the site that are (1) subsurface or otherwise concealed physical conditions that differ materially from those indicated in the Contract Documents or (2) unknown physical conditions of an unusual nature that differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, the Contractor shall promptly provide notice to the Owner, Construction Manager, and the Architect before conditions are disturbed and in no event later than 14 days after first observance of the conditions. The Architect and Construction Manager will promptly investigate such conditions and, if the Architect, in consultation with the Construction Manager, determines that they differ materially and cause an increase or decrease in the Contractor’s cost of, or time required for, performance of any part of the Work, will recommend that an equitable adjustment be made in the Contract Sum or Contract Time, or both. If the Architect, in consultation with the Construction Manager, determines that the conditions at the site are not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract is justified, the Architect shall promptly notify the Owner, Construction Manager, and Contractor, stating the reasons. If the Owner or Contractor disputes the Architect’s determination or recommendation, either party may submit a Claim as provided in Article 15. § 3.7.5 If, in the course of the Work, the Contractor encounters human remains or recognizes the existence of burial markers, archaeological sites or wetlands not indicated in the Contract Documents, the Contractor shall immediately suspend any operations that would affect them and shall notify the Owner, Construction Manager, and Architect. Upon receipt of such notice, the Owner shall promptly take any action necessary to obtain governmental authorization required to resume the operations. The Contractor shall continue to suspend such operations until otherwise instructed by the Owner but shall continue with all other operations that do not affect those remains or features. Requests for adjustments in the Contract Sum and Contract Time arising from the existence of such remains or features may be made as provided in Article 15. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 9 § 3.8 Allowances § 3.8.1 The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents. Items covered by allowances shall be supplied for such amounts and by such persons or entities as the Owner may direct, but the Contractor shall not be required to employ persons or entities to whom the Contractor has reasonable objection. § 3.8.2 Unless otherwise provided in the Contract Documents: .1 allowances shall cover the cost to the Contractor of materials and equipment delivered at the site and all required taxes, less applicable trade discounts; .2 Contractor’s costs for unloading and handling at the site, labor, installation costs, overhead, profit, and other expenses contemplated for stated allowance amounts shall be included in the Contract Sum but not in the allowances; and .3 whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly by Change Order. The amount of the Change Order shall reflect (1) the difference between actual costs and the allowances under Section 3.8.2.1 and (2) changes in Contractor’s costs under Section 3.8.2.2. § 3.8.3 Materials and equipment under an allowance shall be selected by the Owner with reasonable promptness. § 3.9 Superintendent § 3.9.1 The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during performance of the Work. The superintendent shall represent the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor. § 3.9.2 The Contractor, as soon as practicable after award of the Contract, shall notify the Owner and Architect, through the Construction Manager, of the name and qualifications of a proposed superintendent. Within 14 days of receipt of the information, the Construction Manager may notify the Contractor, stating whether the Owner, the Construction Manager, or the Architect (1) has reasonable objection to the proposed superintendent or (2) require additional time for review. Failure of the Construction Manager to provide notice within the 14-day period shall constitute notice of no reasonable objection. § 3.9.3 The Contractor shall not employ a proposed superintendent to whom the Owner, Construction Manager, or Architect has made reasonable and timely objection. The Contractor shall not change the superintendent without the Owner’s consent, which shall not unreasonably be withheld or delayed. § 3.10 Contractor’s Construction and Submittal Schedules § 3.10.1 The Contractor, promptly after being awarded the Contract, shall submit for the Owner’s and Architect’s information, and the Construction Manager’s use in developing the Project schedule, a Contractor’s construction schedule for the Work within the time frame provided in the bidding documents date of substanstial completion. The schedule shall contain detail appropriate for the Project, including (1) the date of commencement of the Work, interim schedule milestone dates, and the date of Substantial Completion; (2) an apportionment of the Work by construction activity; and (3) the time required for completion of each portion of the Work. The schedule shall provide for the orderly progression of the Work to completion and shall not exceed time limits current under the Contract Documents. The schedule shall be revised at appropriate intervals as required by the conditions of the Work and Project. The Contractor shall cooperate with the Construction Manager in scheduling and performing the Contractor’s Work to avoid conflict with, and as to cause no delay in, the work or activities of other Contractors, or the construction or operations of the Owner’s own forces or Separate Contractors. § 3.10.2 The Contractor, promptly after being awarded the Contract and thereafter as necessary to maintain a current submittal schedule, shall submit a submittal schedule for the Construction Manager’s and Architect’s approval. The Architect and Construction Manager’s approval shall not be unreasonably delayed or withheld. The submittal schedule shall (1) be coordinated with the Contractor’s construction schedule, and (2) allow the Construction Manager and Architect reasonable time to review submittals. If the Contractor fails to submit a submittal schedule, or fails to provide submittals in accordance with the approved submittal schedule, the Contractor shall not be entitled to any increase in Contract Sum or extension of Contract Time based on the time required for review of submittals. § 3.10.3 The Contractor shall participate with other Contractors, the Construction Manager, and the Owner in reviewing and coordinating all schedules for incorporation into the Project schedule that is prepared by the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 10 Construction Manager. The Contractor shall make revisions to the construction schedule and submittal schedule as deemed necessary by the Construction Manager to conform to the Project schedule. § 3.10.4 The Contractor shall perform the Work in general accordance with the most recent schedules submitted to the Owner, Construction Manager, and Architect, and incorporated into the approved Project schedule. § 3.11 Documents and Samples at the Site The Contractor shall make available, at the Project site, the Contract Documents, including Change Orders, Construction Change Directives, and other Modifications, in good order and marked currently to indicate field changes and selections made during construction, and the approved Shop Drawings, Product Data, Samples, and similar required submittals. These shall be in electronic form or paper copy, available to the Construction Manager, Architect, and Owner, and delivered to the Construction Manager for submittal to the Owner upon completion of the Work as a record of the Work as constructed. § 3.12 Shop Drawings, Product Data, and Samples § 3.12.1 Shop Drawings are drawings, diagrams, schedules, and other data specially prepared for the Work by the Contractor or a Subcontractor, Sub-subcontractor, manufacturer, supplier, or distributor to illustrate some portion of the Work. § 3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work. § 3.12.3 Samples are physical examples that illustrate materials, equipment, or workmanship, and establish standards by which the Work will be judged. § 3.12.4 Shop Drawings, Product Data, Samples, and similar submittals are not Contract Documents. Their purpose is to demonstrate how the Contractor proposes to conform to the information given and the design concept expressed in the Contract Documents for those portions of the Work for which the Contract Documents require submittals. Review by the Architect and Construction Manager is subject to the limitations of Sections 4.2.10 through 4.2.12. Informational submittals upon which the Construction Manager and Architect are not expected to take responsive action may be so identified in the Contract Documents. Submittals that are not required by the Contract Documents may be returned by the Construction Manager or Architect without action. § 3.12.5 The Contractor shall review for compliance with the Contract Documents, approve, and submit to the Construction Manager, Shop Drawings, Product Data, Samples, and similar submittals required by the Contract Documents, in accordance with the Project submittal schedule approved by the Construction Manager and Architect or, in the absence of an approved Project submittal schedule, with reasonable promptness and in such sequence as to cause no delay in the Work or in the activities of other Contractors, Separate Contractors, or the Owner’s own forces. The Contractor shall cooperate with the Construction Manager in the coordination of the Contractor’s Shop Drawings, Product Data, Samples, and similar submittals with related documents submitted by other Contractors. § 3.12.6 By submitting Shop Drawings, Product Data, Samples, and similar submittals, the Contractor represents to the Owner, Construction Manager, and Architect, that the Contractor has (1) reviewed and approved them, (2) determined and verified materials, field measurements and field construction criteria related thereto, or will do so, and (3) checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. § 3.12.7 The Contractor shall perform no portion of the Work for which the Contract Documents require submittal and review of Shop Drawings, Product Data, Samples, or similar submittals, until the respective submittal has been reviewed and approved by the Architect. § 3.12.8 The Work shall be in accordance with approved submittals except that the Contractor shall not be relieved of responsibility for deviations from the requirements of the Contract Documents by the Architect’s approval of Shop Drawings, Product Data, Samples, or similar submittals, unless the Contractor has specifically notified the Construction Manager and Architect of such deviation at the time of submittal and (1) the Architect has given written approval to the specific deviation as a minor change in the Work, or (2) a Change Order or Construction Change Directive has been Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 11 issued authorizing the deviation. The Contractor shall not be relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples, or similar submittals, by the Architect’s approval thereof. § 3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data, Samples, or similar submittals, to revisions other than those requested by the Construction Manager and Architect on previous submittals. In the absence of such notice, the Architect’s approval of a resubmission shall not apply to such revisions. § 3.12.10 The Contractor shall not be required to provide professional services that constitute the practice of architecture or engineering unless such services are specifically required by the Contract Documents for a portion of the Work or unless the Contractor needs to provide such services in order to carry out the Contractor’s responsibilities for construction means, methods, techniques, sequences, and procedures. The Contractor shall not be required to provide professional services in violation of applicable law. § 3.12.10.1 If professional design services or certifications by a design professional related to systems, materials, or equipment are specifically required of the Contractor by the Contract Documents, the Owner and the Architect will specify all performance and design criteria that such services must satisfy. The Contractor shall be entitled to rely upon the adequacy and accuracy of the performance and design criteria provided in the Contract Documents. The Contractor shall cause such services or certifications to be provided by an appropriately licensed design professional, whose signature and seal shall appear on all drawings, calculations, specifications, certifications, Shop Drawings, and other submittals prepared by such professional. Shop Drawings, and other submittals related to the Work, designed or certified by such professional, if prepared by others, shall bear such professional’s written approval when submitted to the Architect. The Owner, the Architect, and the Construction Manager shall be entitled to rely upon the adequacy and accuracy of the services, certifications, and approvals performed or provided by such design professionals, provided the Owner and Architect have specified to the Contractor the performance and design criteria that such services must satisfy. Pursuant to this Section 3.12.10, the Architect will review and approve or take other appropriate action on submittals only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Construction Manager shall review submittals for sequencing, constructability, and coordination impacts on other Contractors. § 3.12.10.2 If the Contract Documents require the Contractor’s design professional to certify that the Work has been performed in accordance with the design criteria, the Contractor shall furnish such certifications to the Construction Manager and Architect at the time and in the form specified by the Architect. § 3.13 Use of Site § 3.13.1 The Contractor shall confine operations at the site to areas permitted by applicable laws, statutes, ordinances, codes, rules and regulations, lawful orders of public authorities, and the Contract Documents and shall not unreasonably encumber the site with materials or equipment. § 3.13.2 The Contractor shall coordinate the Contractor’s operations with, and secure the approval of, the Construction Manager before using any portion of the site. § 3.14 Cutting and Patching § 3.14.1 The Contractor shall be responsible for cutting, fitting, or patching required to complete the Work or to make its parts fit together properly. All areas requiring cutting, fitting, or patching shall be restored to the condition existing prior to the cutting, fitting, or patching, unless otherwise required by the Contract Documents. § 3.14.2 The Contractor shall not damage or endanger a portion of the Work or fully or partially completed construction of the Owner, Separate Contractors, or of other Contractors by cutting, patching, or otherwise altering such construction, or by excavation. The Contractor shall not cut or otherwise alter construction by the Owner, Separate Contractors, or by other Contractors except with written consent of the Construction Manager, Owner, and such other Contractors or Separate Contractors. Consent shall not be unreasonably withheld. The Contractor shall not unreasonably withhold, from the Separate Contractors, other Contractors, or the Owner, its consent to cutting or otherwise altering the Work. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 12 § 3.15 Cleaning Up § 3.15.1 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials and rubbish caused by operations under the Contract. At completion of the Work, the Contractor shall remove waste materials, rubbish, the Contractor’s tools, construction equipment, machinery, and surplus materials from and about the Project. § 3.15.2 If the Contractor fails to clean up as provided in the Contract Documents, the Owner, or Construction Manager with the Owner’s approval, may do so and the Owner shall be entitled to reimbursement from the Contractor. § 3.16 Access to Work The Contractor shall provide the Owner, Construction Manager, and Architect with access to the Work in preparation and progress wherever located. § 3.17 Royalties, Patents and Copyrights The Contractor shall pay all royalties and license fees. The Contractor shall defend suits or claims for infringement of copyrights and patent rights and shall hold the Owner, Construction Manager, and Architect harmless from loss on account thereof, but shall not be responsible for defense or loss when a particular design, process, or product of a particular manufacturer or manufacturers is required by the Contract Documents, or where the copyright violations are contained in Drawings, Specifications, or other documents prepared by the Owner, Architect, or Construction Manager. However, if an infringement of a copyright or patent is discovered by, or made known to, the Contractor, the Contractor shall be responsible for the loss unless the information is promptly furnished to the Architect through the Construction Manager. § 3.18 Indemnification § 3.18.1 To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the Owner, Construction Manager, Architect, Construction Manager’s and Architect’s consultants, and agents and employees of any of them from and against claims, damages, losses, and expenses, including but not limited to attorneys’ fees, arising out of or resulting from performance of the Work, provided that such claim, damage, loss, or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself), but only to the extent caused by the negligent acts or omissions of the Contractor, a Subcontractor, anyone directly or indirectly employed by them, or anyone for whose acts they may be liable, regardless of whether or not such claim, damage, loss, or expense is caused in part by a party indemnified hereunder. Such obligation shall not be construed to negate, abridge, or reduce other rights or obligations of indemnity that would otherwise exist as to a party or person described in this Section 3.18. § 3.18.2 In claims against any person or entity indemnified under this Section 3.18 by an employee of the Contractor, a Subcontractor, anyone directly or indirectly employed by them, or anyone for whose acts they may be liable, the indemnification obligation under Section 3.18.1 shall not be limited by a limitation on amount or type of damages, compensation, or benefits payable by or for the Contractor or a Subcontractor under workers’ compensation acts, disability benefit acts, or other employee benefit acts. ARTICLE 4 ARCHITECT AND CONSTRUCTION MANAGER § 4.1 General § 4.1.1 The Architect is the person or entity retained by the Owner pursuant to Section 2.3.2 and identified as such in the Agreement. § 4.1.2 The Construction Manager is the person or entity retained by the Owner pursuant to Section 2.3.3 and identified as such in the Agreement. § 4.1.3 Duties, responsibilities, and limitations of authority of the Construction Manager and Architect as set forth in the Contract Documents shall not be restricted, modified, or extended without written consent of the Owner, Construction Manager, Architect, and Contractor. Consent shall not be unreasonably withheld. § 4.2 Administration of the Contract § 4.2.1 The Construction Manager and Architect will provide administration of the Contract as described in the Contract Documents and will be the Owner’s representatives during construction until the date the Architect issues the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 13 final Certificate for Payment. The Construction Manager and Architect will have authority to act on behalf of the Owner only to the extent provided in the Contract Documents. § 4.2.2 The Architect will visit the site at intervals appropriate to the stage of construction, or as otherwise agreed with the Owner, to become generally familiar with the progress and quality of the portion of the Work completed, and to determine in general if the Work observed is being performed in a manner indicating that the Work, when fully completed, will be in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On the basis of the site visits, the Architect will keep the Owner and the Construction Manager reasonably informed about the progress and quality of the portion of the Work completed, and promptly report to the Owner and Construction Manager known deviations from the Contract Documents and defects and deficiencies observed in the Work. § 4.2.3 The Construction Manager shall provide one or more representatives who shall be in attendance at the Project site whenever the Work is being performed.The Construction Manager will determine in general if the Work observed is being performed in accordance with the Contract Documents, will keep the Owner and Architect reasonably informed of the progress of the Work, and will promptly report to the Owner and Architect known deviations from the Contract Documents and the most recent Project schedule, and defects and deficiencies observed in the Work. § 4.2.4 The Construction Manager will schedule and coordinate the activities of the Contractor and other Contractors in accordance with the latest approved Project schedule. § 4.2.5 The Construction Manager, except to the extent required by Section 4.2.4, and Architect will not have control over, charge of, or responsibility for, the construction means, methods, techniques, sequences or procedures, or for the safety precautions and programs in connection with the Work, since these are solely the Contractor’s rights and responsibilities under the Contract Documents, and neither will be responsible for the Contractor’s failure to perform the Work in accordance with the requirements of the Contract Documents. Neither the Construction Manager nor the Architect will have control over or charge of, or be responsible for acts or omissions of, the Contractor, Subcontractors, or their agents or employees, or of any other persons or entities performing portions of the Work. § 4.2.6 Communications. The Owner shall communicate with the Contractor and the Construction Manager’s consultants through the Construction Manager about matters arising out of or relating to the Contract Documents. The Owner and Construction Manager shall include the Architect in all communications that relate to or affect the Architect’s services or professional responsibilities. The Owner shall promptly notify the Architect of the substance of any direct communications between the Owner and the Construction Manager otherwise relating to the Project. Communications by and with the Architect’s consultants shall be through the Architect. Communications by and with Subcontractors and suppliers shall be through the Contractor. Communications by and with other Contractors shall be through the Construction Manager. Communications by and with the Owner’s own forces and Separate Contractors shall be through the Owner. The Contract Documents may specify other communication protocols. § 4.2.7 The Construction Manager and Architect will review and certify all Applications for Payment by the Contractor, in accordance with the provisions of Article 9. § 4.2.8 The Architect and Construction Manager have authority to reject Work that does not conform to the Contract Documents, and will notify each other about the rejection. Whenever the Construction Manager considers it necessary or advisable, the Construction Manager will have authority to require inspection or testing of the Work in accordance with Sections 13.4.2 and 13.4.3, upon written authorization of the Owner, whether or not the Work is fabricated, installed or completed. The foregoing authority of the Construction Manager will be subject to the provisions of Sections 4.2.18 through 4.2.20 inclusive, with respect to interpretations and decisions of the Architect. However, neither the Architect’s nor the Construction Manager’s authority to act under this Section 4.2.8 nor a decision made by either of them in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect or the Construction Manager to the Contractor, Subcontractors, suppliers, their agents or employees, or other persons performing any of the Work. § 4.2.9 Utilizing the submittal schedule provided by the Contractor, the Construction Manager shall prepare, and revise as necessary, a Project submittal schedule incorporating information from other Contractors, the Owner, Owner’s consultants, Owner’s Separate Contractors and vendors, governmental agencies, and participants in the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 14 Project under the management of the Construction Manager. The Project submittal schedule and any revisions shall be submitted to the Architect for approval. § 4.2.10 The Construction Manager will receive and promptly review for conformance with the submittal requirements of the Contract Documents, all submittals from the Contractor such as Shop Drawings, Product Data, and Samples. Where there are other Contractors, the Construction Manager will also check and coordinate the information contained within each submittal received from the Contractor and other Contractors, and transmit to the Architect those recommended for approval. By submitting Shop Drawings, Product Data, Samples, and similar submittals, the Construction Manager represents to the Owner and Architect that the Construction Manager has reviewed and recommended them for approval. The Construction Manager’s actions will be taken in accordance with the Project submittal schedule approved by the Architect or, in the absence of an approved Project submittal schedule, with reasonable promptness while allowing sufficient time to permit adequate review by the Architect. § 4.2.11 The Architect will review and approve, or take other appropriate action upon, the Contractor’s submittals such as Shop Drawings, Product Data, and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect’s action will be taken in accordance with the submittal schedule approved by the Architect or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time in the Architect’s professional judgment to permit adequate review. Upon the Architect’s completed review, the Architect shall transmit its submittal review to the Construction Manager. § 4.2.12 Review of the Contractor’s submittals by the Construction Manager and Architect is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the Contract Documents. The Construction Manager and Architect’s review of the Contractor’s submittals shall not relieve the Contractor of the obligations under Sections 3.3, 3.5, and 3.12. The Construction Manager and Architect’s review shall not constitute approval of safety precautions or of any construction means, methods, techniques, sequences, or procedures. The Architect’s approval of a specific item shall not indicate approval of an assembly of which the item is a component. § 4.2.13 The Construction Manager will prepare Change Orders and Construction Change Directives. § 4.2.14 The Construction Manager and the Architect will take appropriate action on Change Orders or Construction Change Directives in accordance with Article 7, and the Architect will have authority to order minor changes in the Work as provided in Section 7.4. The Architect, in consultation with the Construction Manager, will investigate and make determinations and recommendations regarding concealed and unknown conditions as provided in Section 3.7.4. § 4.2.15 Utilizing the documents provided by the Contractor, the Construction Manager will maintain at the site for the Owner one copy of all Contract Documents, approved Shop Drawings, Product Data, Samples, and similar required submittals, in good order and marked currently to record all changes and selections made during construction. These will be available to the Architect and the Contractor, and will be delivered to the Owner upon completion of the Project. § 4.2.16 The Construction Manager will assist the Architect in conducting inspections to determine the date or dates of Substantial Completion and the date of final completion; issue Certificates of Substantial Completion in conjunction with the Architect pursuant to Section 9.8; and receive and forward to the Owner written warranties and related documents required by the Contract and assembled by the Contractor pursuant to Section 9.10. The Construction Manager will forward to the Architect a final Application and Certificate for Payment or final Project Application and Project Certificate for Payment upon the Contractor’s compliance with the requirements of the Contract Documents. § 4.2.17 If the Owner and Architect agree, the Architect will provide one or more Project representatives to assist in carrying out the Architect’s responsibilities at the site. The Owner shall notify the Construction Manager of any change in the duties, responsibilities and limitations of authority of the Project representatives. § 4.2.18 The Architect will interpret and decide matters concerning performance under, and requirements of, the Contract Documents on written request of the Construction Manager, Owner, or Contractor through the Construction Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 15 Manager. The Architect’s response to such requests will be made in writing within any time limits agreed upon or otherwise with reasonable promptness. § 4.2.19 Interpretations and decisions of the Architect will be consistent with the intent of, and reasonably inferable from, the Contract Documents and will be in writing or in the form of drawings. When making such interpretations and decisions, the Architect will endeavor to secure faithful performance by both Owner and Contractor, will not show partiality to either.. § 4.2.20 The Architect’s decisions on matters relating to aesthetic effect will be final if consistent with the intent expressed in the Contract Documents. § 4.2.21 The Construction Manager will receive and review requests for information from the Contractor, and forward each request for information to the Architect, with the Construction Manager’s recommendation. The Architect will review and respond in writing, through the Construction Manager, to requests for information about the Contract Documents. The Construction Manager’s recommendation and the Architect’s response to each request will be made in writing within any time limits agreed upon or otherwise with reasonable promptness. If appropriate, the Architect will prepare and issue supplemental Drawings and Specifications in response to the requests for information. ARTICLE 5 SUBCONTRACTORS § 5.1 Definitions § 5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the Work at the site. The term "Subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not include other Contractors or Separate Contractors or the subcontractors of other Contractors or Separate Contractors. § 5.1.2 A Sub-subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform a portion of the Work at the site. The term "Sub-subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Sub-subcontractor or an authorized representative of the Sub-subcontractor. § 5.2 Award of Subcontracts and Other Contracts for Portions of the Work § 5.2.1 Unless otherwise stated in the Contract Documents, the Contractor, as soon as practicable after award of the Contract, shall notify the Construction Manager, for review by the Owner, Construction Manager and Architect, of the persons or entities proposed for each principal portion of the Work, including those who are to furnish materials or equipment fabricated to a special design. Within 14 days of receipt of the information, the Construction Manager may notify the Contractor whether the Owner, the Construction Manager or the Architect (1) has reasonable objection to any such proposed person or entity or, (2) requires additional time for review.Failure of the Construction Manager to provide notice within the 14-day period shall constitute notice of no reasonable objection. § 5.2.2 The Contractor shall not contract with a proposed person or entity to whom the Owner, Construction Manager or Architect has made reasonable and timely objection. The Contractor shall not be required to contract with anyone to whom the Contractor has made reasonable objection. § 5.2.3 If the Owner, Construction Manager or Architect has reasonable objection to a person or entity proposed by the Contractor, the Contractor shall propose another to whom the Owner, Construction Manager or Architect has no reasonable objection. If the proposed but rejected Subcontractor was reasonably capable of performing the Work, the Contract Sum and Contract Time shall be increased or decreased by the difference, if any, occasioned by such change, and an appropriate Change Order shall be issued before commencement of the substitute Subcontractor’s Work. However, no increase in the Contract Sum or Contract Time shall be allowed for such change unless the Contractor has acted promptly and responsively in submitting names as required. § 5.2.4 The Contractor shall not substitute a Subcontractor, person, or entity for one previously selected if the Owner, Construction Manager or Architect makes reasonable objection to such substitution. § 5.3 Subcontractual Relations By appropriate written agreement, the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by terms of the Contract Documents, and to assume toward the Contractor all the obligations and responsibilities, including the responsibility for safety of the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 16 Subcontractor’s Work, that the Contractor, by these Contract Documents, assumes toward the Owner, Construction Manager and Architect. Each subcontract agreement shall preserve and protect the rights of the Owner, Construction Manager and Architect under the Contract Documents with respect to the Work to be performed by the Subcontractor so that subcontracting thereof will not prejudice such rights, and shall allow to the Subcontractor, unless specifically provided otherwise in the subcontract agreement, the benefit of all rights, remedies, and redress against the Contractor that the Contractor, by the Contract Documents, has against the Owner. Where appropriate, the Contractor shall require each Subcontractor to enter into similar agreements with Sub-subcontractors. The Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract agreement, copies of the Contract Documents to which the Subcontractor will be bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and conditions of the proposed subcontract agreement that may be at variance with the Contract Documents. Subcontractors will similarly make copies of applicable portions of such documents available to their respective proposed Sub-subcontractors. § 5.4 Contingent Assignment of Subcontracts § 5.4.1 Each subcontract agreement for a portion of the Work is assigned by the Contractor to the Owner, provided that .1 assignment is effective only after termination of the Contract by the Owner pursuant to the Contract and only for those subcontract agreements that the Owner accepts by notifying the Subcontractor and Contractor; and .2 assignment is subject to the prior rights of the surety, if any, obligated under bond relating to the Contract. When the Owner accepts the assignment of a subcontract agreement, the Owner assumes the Contractor’s rights and obligations under the subcontract. § 5.4.2 Upon such assignment, if the Work has been suspended for more than 30 days, the Subcontractor’s compensation may be equitably adjusted for increases in cost resulting from the suspension, if any. § 5.4.3 Upon assignment to the Owner under this Section 5.4, the Owner may further assign the subcontract to a successor Contractor or other entity. If the Owner assigns the subcontract to a successor Contractor or other entity, the Owner shall not remain legally responsible for all of the successor Contractor’s obligations under the subcontract. ARTICLE 6 CONSTRUCTION BY OWNER OR BY SEPARATE CONTRACTORS § 6.1 Owner’s Right to Perform Construction with Own Forces and to Award Other Contracts § 6.1.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner’s own forces, and with Separate Contractors retained under Conditions of the Contract substantially similar to those of this Contract, including those provisions of the Conditions of the Contract related to insurance and waiver of subrogation. § 6.1.2 When the Owner performs construction or operations with the Owner’s own forces or Separate Contractors, the Owner shall provide for coordination of such forces and Separate Contractors with the Work of the Contractor, who shall cooperate with them. § 6.1.3 Unless otherwise provided in the Contract Documents, when the Owner performs construction or operations related to the Project with the Owner’s own forces or with Separate Contractors, the Owner or its Separate Contractors shall have the same obligations and rights that the Contractor has under the Conditions of the Contract, including, without excluding others, those stated in Article 3, this Article 6, and Articles 10, 11, and 12. § 6.2 Mutual Responsibility § 6.2.1 The Contractor shall afford the Owner’s own forces, Separate Contractors, Construction Manager and other Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities, and shall connect and coordinate the Contractor’s construction and operations with theirs as required by the Contract Documents. § 6.2.2 If part of the Contractor’s Work depends for proper execution or results upon construction or operations by the Owner’s own forces, Separate Contractors or other Contractors, the Contractor shall, prior to proceeding with that portion of the Work, promptly notify the Construction Manager and Architect of apparent discrepancies or defects in the construction or operations by the Owner or Separate Contractor or other Contractors that would render it unsuitable for proper execution and results of the Contractor’s Work. Failure of the Contractor to notify the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 17 Construction Manager and the Architect of apparent discrepancies or defects prior to proceeding with the Work shall constitute an acknowledgment that the Owner’s or Separate Contractor’s or other Contractors’ completed or partially completed construction is fit and proper to receive the Contractor’s Work. The Contractor shall not be responsible for discrepancies or defects in the construction or operations by the Owner or Separate Contractors or other Contractors that are not apparent. § 6.2.3 The Contractor shall reimburse the Owner for costs the Owner incurs, including costs that are payable to a Separate Contractors or to other Contractors, because of the Contractor’s delays, improperly timed activities or defective construction. The Owner shall be responsible to the Contractor for costs the Contractor incurs because of delays, improperly timed activities, damage to the Work or defective construction by the Owner’s own forces, Separate Contractors, or other Contractors. § 6.2.4 The Contractor shall promptly remedy damage that the Contractor wrongfully causes to completed or partially completed construction, or to property of the Owner, Separate Contractors, or other Contractors as provided in Section 10.2.5. § 6.2.5 The Owner, Separate Contractors, and other Contractors shall have the same responsibilities for cutting and patching as are described for the Contractor in Section 3.14. § 6.3 Owner’s Right to Clean Up If a dispute arises among the Contractor, Separate Contractors, other Contractors, and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and the Construction Manager, with notice to the Architect, will allocate the cost among those responsible. ARTICLE 7 CHANGES IN THE WORK § 7.1 General § 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the Contract, by Change Order, Construction Change Directive or order for a minor change in the Work, subject to the limitations stated in this Article 7 and elsewhere in the Contract Documents. No claim for an addition to the maximum Contract sum shall be considered a valid claim unless a written change order procedure is followed as outlined in this section. Verbal authorization for changes must be supported by written approval before being considered valid. § 7.1.2 A Change Order shall be based upon agreement among the Owner, Construction Manager, Architect and Contractor. A Construction Change Directive requires agreement by the Owner, Construction Manager and Architect and may or may not be agreed to by the Contractor. An order for a minor change in the Work may be issued by the Architect alone. § 7.1.3 Changes in the Work shall be performed under applicable provisions of the Contract Documents. The Contractor shall proceed promptly with changes in the Work, unless otherwise provided in the Change Order, Construction Change Directive, or order for a minor change in the Work. § 7.2 Change Orders A Change Order is a written instrument prepared by the Construction Manager and signed by the Owner, Construction Manager, Architect, and Contractor, stating their agreement upon all of the following: .1 The change in the Work; .2 The amount of the adjustment, if any, in the Contract Sum; and .3 The extent of the adjustment, if any, in the Contract Time. § 7.2.2 The Contractor must submit change proposals covering a contemplated Change Order within ten (10) days after request of the Owner, or the Architect or within ten (10) days of the event giving rise to the Contractor’s claim for a change in the Contract Sum or Contract time. No increase in the Contract Sum or extension of the Contract Time will be allowed the Contractor for the cost or time involved in making change proposals. Change proposals will define or confirm in detail the Work which is proposed to be added, deleted, or changed and must include any adjustment which the Contractor believes to be necessary in (i) the Contract Sum, or (ii) the Contract Time. Any proposed adjustment must include detailed documentation including, but not limited to: cost, properly itemized and supported Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 18 by sufficient substantiating data to permit evaluation including cost of labor, materials, supplies and equipment, rental cost of machinery and equipment, additional bond cost, plus a fixed fee for profit and overhead. § 7.2.3 If the Architect determines that a change proposal is appropriate, the Architect will recommend a request for a Change Order or Contract Amendment providing for an appropriate adjustment in the Contract Sum or Contract Time, or both, for further action by the Owner. The Owner will prepare the Change Order form. No such change is effective until the Owner and Contractor sign the Change Order. § 7.2.4 The form used to process a Change Order will be the form provided by Owner. § 7.3 Construction Change Directives § 7.3.1 A Construction Change Directive is a written order prepared by the Construction Manager and signed by the Owner, Construction Manager and Architect, directing a change in the Work prior to agreement on adjustment, if any, in the Contract Sum or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions, or other revisions, the Contract Sum and Contract Time being adjusted accordingly. § 7.3.2 A Construction Change Directive shall be used in the absence of total agreement on the terms of a Change Order. § 7.3.3 If the Construction Change Directive provides for an adjustment to the Contract Sum, the adjustment shall be based on one of the following methods: .1 Mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation; .2 Unit prices stated in the Contract Documents or subsequently agreed upon; .3 Cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; or .4 As provided in Section 7.3.4. § 7.3.4 If the Contractor does not respond promptly or disagrees with the method for adjustment in the Contract Sum, the Construction Manager shall determine the adjustment on the basis of reasonable expenditures and savings of those performing the Work attributable to the change, including, in case of an increase in the Contract Sum, an amount for overhead and profit as set forth in the Agreement, or if no such amount is set forth in the Agreement, a reasonable amount. In such case, and also under Section 7.3.3.3, the Contractor shall keep and present, in such form as the Construction Manager may prescribe, an itemized accounting together with appropriate supporting data. Unless otherwise provided in the Contract Documents, costs for the purposes of this Section 7.3.4 shall be limited to the following: .1 Costs of labor, including applicable payroll taxes, fringe benefits required by agreement or custom, workers’ compensation insurance, and other employee costs approved by the Construction Manager and Architect; .2 Costs of materials, supplies, and equipment, including cost of transportation, whether incorporated or consumed; .3 Rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others; .4 Costs of premiums for all bonds and insurance, permit fees, and sales, use, or similar taxes, directly related to the change; and .5 Costs of supervision and field office personnel directly attributable to the change. § 7.3.5 If the Contractor disagrees with the adjustment in the Contract Time, the Contractor may make a Claim in accordance with applicable provisions of Article 15. § 7.3.6 Upon receipt of a Construction Change Directive, the Contractor shall promptly proceed with the change in the Work involved and advise the Construction Manager of the Contractor’s agreement or disagreement with the method, if any, provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or Contract Time. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 19 § 7.3.7 A Construction Change Directive signed by the Contractor indicates the Contractor’s agreement therewith, including adjustment in Contract Sum and Contract Time or the method for determining them. Such agreement shall be effective immediately and shall be recorded as a Change Order. § 7.3.8 The amount of credit to be allowed by the Contractor to the Owner for a deletion or change that results in a net decrease in the Contract Sum shall be actual net cost as confirmed by the Construction Manager and Architect. When both additions and credits covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. § 7.3.9 Pending final determination of the total cost of a Construction Change Directive to the Owner, the Contractor may request payment for Work completed under the Construction Change Directive in Applications for Payment. The Construction Manager and Architect will make an interim determination for purposes of monthly certification for payment for those costs and certify for payment the amount that the Construction Manager and Architect determine to be reasonably justified. The interim determination of cost shall adjust the Contract Sum on the same basis as a Change Order, subject to the right of either party to disagree and assert a Claim in accordance with Article 15. § 7.3.10 When the Owner and Contractor agree with a determination made by the Construction Manager and Architect concerning the adjustments in the Contract Sum and Contract Time, or otherwise reach agreement upon the adjustments, such agreement shall be effective immediately and the Construction Manager shall prepare a Change Order. Change Orders may be issued for all or any part of a Construction Change Directive. § 7.4 Minor Changes in the Work The Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract Time. The Architect’s order for minor changes shall be in writing. If the Contractor believes that the proposed minor change in the Work will affect the Contract Sum or Contract Time, the Contractor shall notify the Construction Manager and shall not proceed to implement the change in the Work. If the Contractor performs the Work set forth in the Architect’s order for a minor change without prior notice to the Construction Manager that such change will affect the Contract Sum or Contract Time, the Contractor waives any adjustment to the Contract Sum or extension of the Contract Time. ARTICLE 8 TIME § 8.1 Definitions § 8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in the Contract Documents for Substantial Completion of the Work. § 8.1.2 The date of commencement of the Work is the date established in the Agreement. § 8.1.3 The date of Substantial Completion is the date certified by the Architect in accordance with Section 9.8. § 8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless otherwise specifically defined. § 8.2 Progress and Completion § 8.2.1 Time limits stated in the Contract Documents are of the essence of the Contract. By executing the Agreement, the Contractor confirms that the Contract Time is a reasonable period for performing the Work. § 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, commence the Work prior to the effective date of insurance required to be furnished by the Contractor. § 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. If Contractor’s Work shall fall behind schedule for reasons that are not excused under the terms of the Contract, Contractor shall add additional workers or shifts, and/or work overtime as necessary to maintain the Construction Schedule, solely at the Contractor’s expense. § 8.2.4 The Contractor must conform to the most recently approved Construction Schedule. The Contractor must complete the indicated Work or achieve the required percentage of completion, as applicable, within any interim completion dates established in the most recently approved Construction Schedule. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 20 § 8.2.5 Contractor shall maintain at Site, available to Owner and Architect for their reference during progress of Work, a copy of approved Construction Schedule and any approved revisions thereto. Contractor shall keep current records of, and mark on copy of approved Construction Schedule actual commence date, progress, and completion date of each scheduled activity, indicated on Construction Schedule. § 8.2.6 The Contractor represents that its Guaranteed Maximum Price includes all costs, overhead and profit which may be incurred throughout the Contract Time and the period between Substantial and Final Completion. Accordingly, the Contractor may not make any claim for delay damages based in whole or in part on the premise that the Contractor would have completed the Work prior to the expiration of the Contract Time but for any claimed delay. § 8.2.7 If the Contractor’s progress is not maintained in accordance with the approved Construction Schedule, or the Owner determines that the Contractor is not diligently proceeding with the Work or has evidence reasonably indicating that the Contractor will not be able to conform to the most recently approved Construction Schedule, the Contractor must, promptly and at no additional cost to the Owner, take all measurers necessary to accelerate its progress to overcome the delay and ensure that there will be no further delay in the progress of the Work and notify the Owner. § 8.3 Delays and Extensions of Time § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by (1) an act or neglect of the Owner, Architect, Construction Manager, or an employee of any of them, or of the Owner’s own forces, Separate Contractors, or other Contractors; (2) by changes ordered in the Work; (3) by labor disputes, fire, unusual delay in deliveries, unavoidable casualties, adverse weather conditions documented in accordance with Section 15.1.6.2, or other causes beyond the Contractor’s control; (4) by delay authorized by the Owner pending mediation and binding dispute resolution; or (5) by other causes that the Contractor asserts and the Architect, based on the recommendation of the Construction Manager, determines justify delay, then the Contract Time shall be extended for such reasonable time as the Architect may determine. A time extension shall be Contractor’s sole remedy and compensation for all such delays other than those resulting from the acts or negligence of the Owner, the Architect, or the Owner’s separate contractors (collectively "Owner Caused Delays"). For proven Owner Caused Delays, the Contractor may recoup the actual costs resulting from such delays, but not for any additional profit or fee. § 8.3.2 Permissable claims relating to time shall be made in accordance with applicable provisions of Article 15. § 8.3.3 Except as otherwise provided, this Section 8.3 does not preclude recovery of damages for delay by either party under other provisions of the Contract Documents. ARTICLE 9 PAYMENTS AND COMPLETION § 9.1 Contract Sum § 9.1.1 The Contract Sum is stated in the Agreement and, including authorized adjustments, is the total amount payable by the Owner to the Contractor for performance of the Work under the Contract Documents. § 9.1.2 If unit prices are stated in the Contract Documents or subsequently agreed upon, and if quantities originally contemplated are materially changed so that application of such unit prices to the actual quantities causes substantial inequity to the Owner or Contractor, the applicable unit prices shall be equitably adjusted. § 9.2 Schedule of Values Where the Contract is based on a stipulated sum or Guaranteed Maximum Price, the Contractor shall submit a schedule of values to the Construction Manager, before the first Application for Payment, allocating the entire Contract Sum to the various portions of the Work. The schedule of values shall be prepared in the form, and supported by the data to substantiate its accuracy, required by the Construction Manager and the Architect. This schedule, unless objected to by the Construction Manager or Architect, shall be used as a basis for reviewing the Contractor’s Applications for Payment. The Construction Manager shall forward to the Architect the Contractor’s schedule of values. Any changes to the schedule of values shall be submitted to the Construction Manager and supported by such data to substantiate its accuracy as the Construction Manager and the Architect may require, and unless objected to by the Construction Manager or the Architect, shall be used as a basis for reviewing the Contractor’s subsequent Applications for Payment. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 21 § 9.3 Applications for Payment § 9.3.1 At least fifteen days before the date established for each progress payment, the Contractor shall submit to the Construction Manager an itemized Application for Payment prepared in accordance with the schedule of values, if required under Section 9.2, for completed portions of the Work.The application shall be notarized, if required, and supported by all data substantiating the Contractor’s right to payment that the Owner, Construction Manager or Architect require, such as copies of requisitions, and releases of waivers of lien from Subcontractors and suppliers, and shall reflect retainage if provided for in the Contract Documents. § 9.3.1.1 As provided in Section 7.3.9, such applications may include requests for payment on account of changes in the Work that have been properly authorized by Construction Change Directives, or by interim determinations of the Construction Manager and Architect, but not yet included in Change Orders. § 9.3.1.2 Applications for Payment shall not include requests for payment for portions of the Work for which the Contractor does not intend to pay a Subcontractor or supplier, unless such Work has been performed by others whom the Contractor intends to pay. § 9.3.2 Unless otherwise provided in the Contract Documents, payments shall be made on account of materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work. If approved in advance by the Owner, payment may similarly be made for materials and equipment suitably stored off the site at a location agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner’s title to such materials and equipment or otherwise protect the Owner’s interest, and shall include the costs of applicable insurance, storage, and transportation to the site, for such materials and equipment stored off the site. § 9.3.3 The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall, to the best of the Contractor’s knowledge, information, and belief, be free and clear of liens, claims, security interests, or encumbrances, in favor of the Contractor, Subcontractors, suppliers, or other persons or entities that provided labor, materials and equipment relating to the Work. § 9.4 Certificates for Payment § 9.4.1 Where there is only one Contractor, the Construction Manager will, within seven days after the Construction Manager’s receipt of the Contractor’s Application for Payment, review the Application, certify the amount the Construction Manager determines is due the Contractor, and forward the Contractor’s Application and Certificate for Payment to the Architect. Within seven days after the Architect receives the Contractor’s Application for Payment from the Construction Manager, the Architect will either (1) issue to the Owner a Certificate for Payment, in the full amount of the Application for Payment, with a copy to the Construction Manager; or (2) issue to the Owner a Certificate for Payment for such amount as the Architect determines is properly due, and notify the Construction Manager and Owner of the Architect’s reasons for withholding certification in part as provided in Section 9.5.1; or (3) withhold certification of the entire Application for Payment, and notify the Construction Manager and Owner of the Architect’s reason for withholding certification in whole as provided in Section 9.5.1. The Construction Manager will promptly forward to the Contractor the Architect’s notice of withholding certification. § 9.4.2 Where there is more than one Contractor performing portions of the Project, the Construction Manager will, within seven days after the Construction Manager receives all of the Contractors’ Applications for Payment: (1) review the Applications and certify the amount the Construction Manager determines is due each of the Contractors; (2) prepare a Summary of Contractors’ Applications for Payment by combining information from each Contractor’s application with information from similar applications for progress payments from the other Contractors; (3) prepare a Project Application and Certificate for Payment; (4) certify the amount the Construction Manager determines is due all Contractors; and (5) forward the Summary of Contractors’ Applications for Payment and Project Application and Certificate for Payment to the Architect. § 9.4.2.1 Within seven days after the Architect receives the Project Application and Project Certificate for Payment and the Summary of Contractors’ Applications for Payment from the Construction Manager, the Architect will either (1) issue to the Owner a Project Certificate for Payment, with a copy to the Construction Manager; or (2) issue to the Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 22 Owner a Project Certificate for Payment for such amount as the Architect determines is properly due, and notify the Construction Manager and Owner of the Architect’s reasons for withholding certification in part as provided in Section 9.5.1; or (3) withhold certification of the entire Project Application for Payment, and notify the Construction Manager and Owner of the Architect’s reason for withholding certification in whole as provided in Section 9.5.1. The Construction Manager will promptly forward the Architect’s notice of withholding certification to the Contractors. § 9.4.3 The Construction Manager’s certification of an Application for Payment or, in the case of more than one Contractor, a Project Application and Certificate for Payment, shall be based upon the Construction Manager’s evaluation of the Work and the data in the Application or Applications for Payment. The Construction Manager’s certification will constitute a representation that, to the best of the Construction Manager’s knowledge, information, and belief, the Work has progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and that the Contractor is, or Contractors are, entitled to payment in the amount certified. § 9.4.4 The Architect’s issuance of a Certificate for Payment or, in the case of more than one Contractor, Project Application and Certificate for Payment, shall be based upon the Architect’s evaluation of the Work, the recommendation of the Construction Manager, and data in the Application for Payment or Project Application for Payment. The Architect’s certification will constitute a representation that, to the best of the Architect’s knowledge, information, and belief, the Work has progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and that the Contractor is, or Contractors are, entitled to payment in the amount certified. § 9.4.5 The representations made pursuant to Sections 9.4.3 and 9.4.4 are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests and inspections, to correction of minor deviations from the Contract Documents prior to completion, and to specific qualifications expressed by the Construction Manager or Architect. § 9.4.6 The issuance of a Certificate for Payment or a Project Certificate for Payment will not be a representation that the Construction Manager or Architect has (1) made exhaustive or continuous on-site inspections to check the quality or quantity of the Work; (2) reviewed construction means, methods, techniques, sequences, or procedures; (3) reviewed copies of requisitions received from Subcontractors and suppliers and other data requested by the Owner to substantiate the Contractor’s right to payment; or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. § 9.5 Decisions to Withhold Certification § 9.5.1 The Construction Manager or Architect may withhold a Certificate for Payment or Project Certificate for Payment in whole or in part, to the extent reasonably necessary to protect the Owner, if in the Construction Manager’s or Architect’s opinion the representations to the Owner required by Section 9.4.3 and 9.4.4 cannot be made. If the Construction Manager or Architect is unable to certify payment in the amount of the Application, the Construction Manager will notify the Contractor and Owner as provided in Section 9.4.1 and 9.4.2. If the Contractor, Construction Manager and Architect cannot agree on a revised amount, the Architect will promptly issue a Certificate for Payment or a Project Certificate for Payment for the amount for which the Architect is able to make such representations to the Owner. The Construction Manager or Architect may also withhold a Certificate for Payment or, because of subsequently discovered evidence, may nullify the whole or a part of a Certificate for Payment or Project Certificate for Payment previously issued, to such extent as may be necessary in the Construction Manager’s or Architect’s opinion to protect the Owner from loss for which the Contractor is responsible, including loss resulting from the acts and omissions described in Section 3.3.2 because of .1 defective Work not remedied; .2 third party claims filed or reasonable evidence indicating probable filing of such claims, unless security acceptable to the Owner is provided by the Contractor; .3 failure of the Contractor to make payments properly to Subcontractors or suppliers for labor, materials or equipment; .4 reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; .5 damage to the Owner or a Separate Contractor or other Contractor; .6 reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; or .7 repeated failure to carry out the Work in accordance with the Contract Documents; .8 service work not attended to; .9 evidence of lack of careful workmanship; Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 23 .10 unworkmanlike or over expeditious construction; .11 lack of attention to the special field duties specified. § 9.5.2 When either party disputes the Architect’s decision regarding a Certificate for Payment under Section 9.5.1, in whole or in part, that party may submit a Claim in accordance with Article 15. § 9.5.3 When the reasons for withholding certification are removed, certification will be made for amounts previously withheld. § 9.5.4 If the Architect or Construction Manager withholds certification for payment under Section 9.5.1, the Owner may, at its sole option, issue joint checks to the Contractor and to any Subcontractor or supplier to whom the Contractor failed to make payment for Work properly performed or material or equipment suitably delivered. If the Owner makes payments by joint check, the Owner shall notify the Architect and the Construction Manager, and both will reflect such payment on the next Certificate for Payment. § 9.6 Progress Payments § 9.6.1 After the Architect has issued a Certificate for Payment or Project Certificate for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents, and shall so notify the Construction Manager and Architect. § 9.6.2 The Contractor shall pay each Subcontractor, no later than seven days after receipt of payment from the Owner, the amount to which the Subcontractor is entitled, reflecting percentages actually retained from payments to the Contractor on account of the Subcontractor’s portion of the Work. The Contractor shall, by appropriate agreement with each Subcontractor, require each Subcontractor to make payments to Sub-subcontractors in a similar manner. § 9.6.3 The Construction Manager will, on request, furnish to a Subcontractor, if practicable, information regarding percentages of completion or amounts applied for by the Contractor and action taken thereon by the Owner, Construction Manager and Architect on account of portions of the Work done by such Subcontractor. § 9.6.4 The Owner has the right to request written evidence from the Contractor that the Contractor has properly paid Subcontractors and suppliers amounts paid by the Owner to the Contractor for subcontracted Work. If the Contractor fails to furnish such evidence within seven days, the Owner shall have the right to contact Subcontractors and suppliers to ascertain whether they have been properly paid. Neither the Owner, Construction Manager nor Architect shall have an obligation to pay, or to see to the payment of money to, a Subcontractor or supplier, except as may otherwise be required by law. § 9.6.5 The Contractor’s payments to suppliers shall be treated in a manner similar to that provided in Sections 9.6.2, 9.6.3 and 9.6.4. § 9.6.6 A Certificate for Payment, a progress payment, or partial or entire use or occupancy of the Project by the Owner shall not constitute acceptance of Work not in accordance with the Contract Documents. § 9.6.7 Unless the Contractor provides the Owner with a payment bond in the full penal sum of the Contract Sum, payments received by the Contractor for Work properly performed by Subcontractors or provided by suppliers shall be held by the Contractor for those Subcontractors or suppliers who performed Work or furnished materials, or both, under contract with the Contractor for which payment was made by the Owner. § 9.6.8 Provided the Owner has fulfilled its payment obligations under the Contract Documents, the Contractor shall defend and indemnify the Owner from all loss, liability, damage or expense, including reasonable attorney’s fees and litigation expenses, arising out of any Iowa Code Chapter 573 claim or other claim for payment by any Subcontractor or supplier of any tier. Upon receipt of notice of an Iowa Code Chapter 573 claim or other claim for payment, the Owner shall notify the Contractor. If approved by the applicable court, when required, the Contractor may substitute a surety bond for the property against which the Iowa Code Chapter 573 or other claim for payment has been asserted. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 24 § 9.7 Failure of Payment If Owner does not pay the Contractor within sixty (60) days after the Construction Manager and Architect issue a Certificate for Payment or a Project Certificate for Payment, through no fault of the Contractor, the Contractor may file a claim in accordance with Article 15 of this Contract. § 9.8 Substantial Completion § 9.8.1 Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so the Owner can occupy or utilize the Work for its intended use. § 9.8.2 When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor shall notify the Construction Manager, and the Contractor and Construction Manager shall jointly prepare and submit to the Architect a comprehensive list of items to be completed or corrected prior to final payment. Failure to include an item on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. § 9.8.3 Upon receipt of the list, the Architect, assisted by the Construction Manager, will make an inspection to determine whether the Work or designated portion thereof is substantially complete. If the Architect’s inspection discloses any item, whether or not included on the list, which is not sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work or designated portion thereof for its intended use, the Contractor shall, before issuance of the Certificate of Substantial Completion, complete or correct such item upon notification by the Architect. In such case, the Contractor shall then submit a request for another inspection by the Architect, assisted by the Construction Manager, to determine Substantial Completion. § 9.8.4 When the Architect, assisted by the Construction Manager, determines that the Work of all of the Contractors, or designated portion thereof, is substantially complete, the Construction Manager will prepare, and the Construction Manager and Architect shall execute, a Certificate of Substantial Completion that shall establish the date of Substantial Completion; establish responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance; and fix the time within which the Contractor shall finish all items on the list accompanying the Certificate. However, warranties required by the Contract Documents shall not commence until the date Owner has issued a final acceptance of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion. § 9.8.5 The Certificate of Substantial Completion shall be submitted to the Owner and Contractor for their written acceptance of responsibilities assigned to them in the Certificate. Upon such acceptance, and consent of surety if any, the Owner shall make payment of retainage applying to the Work or designated portion thereof in the manner provided under applicable Iowa law and this section 9.8. Such payment shall be adjusted for Work that is incomplete or not in accordance with the requirements of the Contract Documents. § 9.8.6 The Certificate of Substantial Completion and accompanying Punch List must be submitted to the Owner and Contractor for execution, which will constitute their written acceptance of responsibilities assigned to them in such Certificate. Contractor must make all corrections on the punch list prior to notifying Architect of its completion as outlined in Section 9.10. The Contractor shall reimburse the Owner for any Architect’s additional services or attorney’s fees incurred as a result of Contractor’s failure to finally complete the Work within sixty (60) days after the date specified in the Contract Documents for Project Substantial Completion, or subsequently modified by Change Orders or dates established in the Certificate of Substantial Completion. Reimbursement for these Additional Services will be deducted by the Owner from the amounts due the Contractor and paid directly to the Architect. For purposes of this paragraph "incurred as a result of" includes any architectural fees charged to Owner as Additional Fees under the contract due to the fact that the services were performed sixty (60) days (or some other amount of time specified in the Owner/Architect Agreement) after Substantial Completion. The nature of the services performed (and whether they would have otherwise been performed as normal closeout services at some point under Basic Services) is not relevant to the Contractor’s obligations for reimbursement under this section if the contract between the Owner and Architect states that any and all services and related fees are defined as Additional Services solely because they were performed more than sixty (60) days (or some other amount of time specified in the Owner/Architect Agreement) after Substantial Completion. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 25 § 9.8.7 Request for Early Release of Retainage Funds: Upon achieving Substantial Completion, as defined by Iowa law, the Contractor may formally request the release of all or part of the retainage funds being held on the Project. The Contractors’ request for Release of the Retainage Funds shall be accompanied by a sworn statement that ten (10) calendar days prior to filing the Request for Release of the Funds a notice was given to all known subcontractors, sub-subcontractors and suppliers that the Contractor is requesting the early release of retainage funds. If proper documentation is received from the Contractor, the Owner will release all retainage funds at the next monthly Council meeting or within thirty (30) days, whichever is less, except it may retain the following to the extent authorized by law: a) An amount equal to 200% of the value of labor or materials yet to be provided on the Project as determined by the Owner and its authorized contract representative. For purposes of this section, "authorized contract representative" means the Architect of record on the Project, unless otherwise specified. b) An amount equal to 200% of the value of any Chapter 573 claims currently on file at the time the Request for Release of Retainage is approved. c) An amount equal to one-half percent (½%) of the total value of the Project for Operation, Maintenance and Warranty Manuals and Record Drawings and Specifications not submitted ten (10) days prior to Substantial Completion inspection. If the Owner withholds an amount from the retainage payment to the Contractor, the Owner will provide a reason the request is being denied to the Contractor within thirty (30) calendar days of the receipt of the request. § 9.8.8 Warranties required by the Contract Documents will commence on the Date of Final Completion of the Work unless otherwise provided in the Certificate of Substantial Completion or the Contract Documents. § 9.8.9 Upon execution of the Certificate of Substantial Completion, the Contractor will deliver custody and control of such Work to the Owner. The Owner will thereafter provide the Contractor reasonable access to such Work to permit the Contractor to fulfill the correction, completion and other responsibilities remaining under the Contract and the Certificate of Substantial Completion. § 9.8.10 Unless otherwise provided in the Certificate of Substantial Completion, the Contractor must complete or correct all items included in the final Punch List within sixty (60) days, subject to the availability of special order parts and materials, after the Date of Substantial Completion. § 9.8.11 At the time of Substantial Completion, in addition to removing rubbish and leaving the building "broom clean," the Contractor must replace any broken or damaged materials, remove stains, spots, marks and dirt from decorated Work, clean all fixtures, vacuum all carpets and wet mop all other floors, replace HVAC filters, clean HVAC coils, and comply with such additional requirements, if any, which may be specified in the Contract Documents. § 9.9 Partial Occupancy or Use § 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor and Construction Manager shall jointly prepare and submit a list to the Architect as provided under Section 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Contractor or, if no agreement is reached, by decision of the Architect after consultation with the Construction Manager. § 9.9.2 Immediately prior to such partial occupancy or use, the Owner, Construction Manager, Contractor, and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 26 § 9.9.3 Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents. § 9.10 Final Completion and Final Payment § 9.10.1 Upon completion of the Work, the Contractor shall forward to the Construction Manager a notice that the Work is ready for final inspection and acceptance, and shall also forward to the Construction Manager a final Contractor’s Application for Payment. Upon receipt, the Construction Manager shall perform an inspection to confirm the completion of Work of the Contractor. The Construction Manager shall make recommendations to the Architect when the Work of all of the Contractors is ready for final inspection, and shall then forward the Contractors’ notices and Application for Payment or Project Application for Payment, to the Architect, who will promptly make such inspection. When the Architect finds the Work acceptable under the Contract Documents and the Contract fully performed, the Construction Manager and Architect will promptly issue a final Certificate for Payment or Project Certificate for Payment stating that to the best of their knowledge, information and belief, and on the basis of their on-site visits and inspections, the Work has been completed in accordance with the Contract Documents and that the entire balance found to be due the Contractor and noted in the final Certificate is due and payable. The Construction Manager’s and Architect’s final Certificate for Payment or Project Certificate for Payment will constitute a further representation that conditions listed in Section 9.10.2 as precedent to the Contractor’s being entitled to final payment have been fulfilled. § 9.10.2 Neither final payment nor any remaining retained percentage shall become due until the Contractor submits to the Architect through the Construction Manager (1) an affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner’s property might be responsible or encumbered (less amounts withheld by Owner) have been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is currently in effect, (3) a written statement that the Contractor knows of no reason that the insurance will not be renewable to cover the period required by the Contract Documents, (4) consent of surety, if any, to final payment (5) documentation of any special warranties, such as manufacturers’ warranties or specific Subcontractor warranties, and (6), if required by the Owner, other data establishing payment or satisfaction of obligations, such as receipts and releases and waivers of liens, claims, security interests, or encumbrances arising out of the Contract, to the extent and in such form as may be designated by the Owner. If a Subcontractor refuses to furnish a release or waiver required by the Owner, the Contractor may furnish a bond satisfactory to the Owner to indemnify the Owner against such lien, claim, security interest, or encumbrance. If a lien, claim, security interest, or encumbrance remains unsatisfied after payments are made, the Contractor shall refund to the Owner all money that the Owner may be compelled to pay in discharging the lien, claim, security interest, or encumbrance, including all costs and reasonable attorneys’ fees. (Paragraphs deleted) § 9.10.3 Final payment will be made no earlier than thirty-one (31) days following approval by the Owner’s City Council at a regularly scheduled meeting, receipt of all Chapter 573 Claim Releases, Sales Tax information, and all other required closeout documents, and subject to the conditions of and in accordance with the provisions of Iowa Code Chapter 573 and Iowa Code Chapter 26. Owner may withhold from final payment any and all amounts required to reimburse the Owner for all costs, fees (including reasonable attorney’s fees) it incurred as a result of any Chapter 573 Claims filed on the Project. Neither final payment nor any remaining retained percentage will become due until the Contractor submits the following documents to the Architect: .1 An Affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner’s property might be responsible or encumbered (less amounts withheld by Owner), have been paid or otherwise satisfied, submitted on AIA Document G706, Affidavit of Payment of Debts and Claims (latest edition) or such other form as may be prescribed by the Owner; .2 A release or waiver of liens and Iowa Code Chapter 573 claims, on behalf of the Contractor and a similar release or waiver on behalf of each Subcontractor and supplier, accompanied by AIA Document G706A, Affidavit of Release of Liens (latest edition) or such other form as may be prescribed by the Owner; .3 A certificate evidencing that the Contractor’s liability insurance and Performance Bond remain in effect during the one-year correction period following Substantial Completion as set forth in Section 12.2.2.1 and 12.2.2.2; .4 A written statement that the Contractor knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract Documents; Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 27 .5 Consent of surety to final payment, submitted on AIA Document G707 (latest edition) or other form prescribed by the Owner; .6 Other data required by the Owner establishing payment or satisfaction of obligations, such as receipts, releases and waivers of claims, security interests or encumbrances arising out of the Contract, to the extent and in such form as may be prescribed by the Owner; .7 A certified building location survey and as-built site plan in the form and number required by the Contract Documents; .8 All warranties and bonds required by the Contract Documents; and .9 Record Documents and return of Contract Documents as provided therein. § 9.10.4 Final acceptance of construction by the Owner is final approval of the Project only in the sense that it has been constructed, cleaned up, and completed in apparent substantial compliance with the Contract Documents. Said final acceptance is stipulated to mean a written acceptance by the Owner’s City Council. The certificate of completion submitted by Owner’s representative and approved by the Owner’s City Council shall constitute final acceptance of the Work and materials included in the Contract on the date of such approval, subject to the provision any such approval, acceptance, or payment as herein provided shall not constitute an acceptance of any unauthorized or defective work, or of any improper work or material. § 9.10.5 Acceptance of final payment by the Contractor, a Subcontractor, or a supplier, shall constitute a waiver of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of final Application for Payment. § 9.11 ASSIGNMENT § 9.11.1 No assignment by the Contractor of any principal contract or any part thereof, or of the funds to be received thereunder by the Contractor, will be recognized unless such assignment has had the written approval of the Owner and the Surety has been given due notice of such assignment and has furnished written consent thereto. In addition to the usual recitals in the Assignment Contract, the following language must be set forth: "It is agreed that the funds to be paid to the Assignee under this Assignment are subject to prior lien/Iowa Code Chapter 573 claims for services rendered on materials supplied for the performance of all work called for in said Contract, in favor of all persons, firms or corporations rendering such services supplying such materials." ARTICLE 10 PROTECTION OF PERSONS AND PROPERTY § 10.1 Safety Precautions and Programs The Contractor shall be responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the performance of the Contract. The Contractor shall submit the Contractor’s safety program to the Construction Manager for review and coordination with the safety programs of other Contractors. The Construction Manager’s responsibilities for review and coordination of safety programs shall not extend to direct control over or charge of the acts or omissions of the Contractors, Subcontractors, agents or employees of the Contractors or Subcontractors, or any other persons performing portions of the Work and not directly employed by the Construction Manager. § 10.2 Safety of Persons and Property § 10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide reasonable protection to prevent damage, injury, or loss to .1 employees on the Work and other persons who may be affected thereby; .2 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site, under care, custody, or control of the Contractor, a Subcontractor, or a Sub-subcontractor; .3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures, and utilities not designated for removal, relocation, or replacement in the course of construction; and Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 28 .4 construction or operations by the Owner, Separate Contractors, or other Contractors. § 10.2.2 The Contractor shall comply with, and give notices required by applicable laws, statutes, ordinances, codes, rules and regulations, and lawful orders of public authorities, bearing on safety of persons or property or their protection from damage, injury, or loss. § 10.2.3 The Contractor shall implement, erect, and maintain, as required by existing conditions and performance of the Contract, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards; promulgating safety regulations; and notifying the owners and users of adjacent sites and utilities of the safeguards. § 10.2.4 When use or storage of explosives or other hazardous materials or equipment or unusual methods are necessary for execution of the Work, the Contractor shall exercise utmost care and carry on such activities under supervision of properly qualified personnel. § 10.2.5 The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Contract Documents) to property referred to in Sections 10.2.1.2, 10.2.1.3 and 10.2.1.4 caused in whole or in part by the Contractor, a Subcontractor, a Sub-subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Sections 10.2.1.2, 10.2.1.3 and 10.2.1.4. The foregoing obligations of the Contractor are in addition to the Contractor’s obligations under Section 3.18. § 10.2.6 The Contractor shall designate a responsible member of the Contractor’s organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor’s superintendent unless otherwise designated by the Contractor in writing to the Owner, Construction Manager and Architect. § 10.2.7 The Contractor shall not permit any part of the construction or site to be loaded so as to cause damage or create an unsafe condition. § 10.2.8 Injury or Damage to Person or Property If either party suffers injury or damage to person or property because of an act or omission of the other party, or of others for whose acts such party is legally responsible, notice of the injury or damage, whether or not insured, shall be given to the other party within a reasonable time not exceeding 21 days after discovery. The notice shall provide sufficient detail to enable the other party to investigate the matter. § 10.2.9 Contractor shall at all times, protect the excavation, trenches and/or the buildings from damage or rain water, spring water, ground water, backing up of drains, or sewers, etc., and provide all pumps, equipment, and enclosures to give this protection. Contractor shall provide all shoring, bracing, and sheeting as required for safety and for the proper execution of the Work, and shall remove when the Work is completed. At the end of the day’s work, all new work likely to be damaged shall be covered. During cold weather, the Contractor shall protect all work from damage at no additional expense to the Owner. If low temperatures make it impossible to continue operations safely in spite of cold weather precautions, work shall cease after notifying Owner and Architect. All other protective measures not mentioned above which may be required shall be furnished by the Contractor. § 10.2.10 The Owner has attempted to show on the plans all aboveground and underground facilities, including public and private utilities, which may be affected by the work. The location, depth, and size of each such facility shown on the plans is approximate only and is not guaranteed. Other underground facilities may exist, and their location may not be presently known or identified. It is the Contractor’s responsibility to determine the existence and exact location of all such facilities located within the construction area to avoid damage. Where existing facilities are shown in the Contract Documents or encountered within the construction area, it shall be the responsibility of the Contractor to notify the operators of those facilities prior to beginning any construction activities. The Contractor shall allow access to those facilities for necessary modification of services. The Contractor shall support, sustain, and protect existing pipes, conduits, poles, wires, and other apparatus located under, over, along, across, or adjacent to the work site. If such utilities are damaged through Contractor’s Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 29 negligence, they will be repaired by the agencies having control of same, but the cost of such repairs shall be paid by the Contractor. The Contractor shall, prior to commencing any excavation or other operation that may affect underground facilities, notify the "Iowa One Call" underground facility locate system, established pursuant to Iowa Code Chapter 480. The Contractor shall, if requested by the operator of an underground facility, assist in the location of its facilities; provided, however, the Owner shall not be responsible to the Contractor or to any operator of an underground facility for the cost of locating such facility, or for any damage to such facility that occurs in attempting to locate it, or for any damage to the facility occasioned by the Contractor’s performance of work under the contract. Claims for additional compensation will not be allowed to the Contractor for any interference, delay, or additional work occasioned by the location or adjustment of aboveground or underground facilities, or connections thereto. § 10.3 Hazardous Materials § 10.3.1 The Contractor is responsible for compliance with any requirements included in the Contract Documents regarding hazardous materials or substances. If the Contractor encounters a hazardous material or substance not addressed in the Contract Documents and if reasonable precautions will be inadequate to prevent foreseeable bodily injury or death to persons resulting from a material or substance, including but not limited to asbestos or polychlorinated biphenyl (PCB), encountered on the site by the Contractor, the Contractor shall, upon recognizing the condition, immediately stop Work in the affected area and notify the Owner, Construction Manager and Architect of the condition. § 10.3.2 Upon receipt of the Contractor’s notice, the Owner shall obtain the services of a licensed laboratory to verify the presence or absence of the material or substance reported by the Contractor and, in the event such material or substance is found to be present, to cause it to be rendered harmless. Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the Contractor, Construction Manager and Architect the names and qualifications of persons or entities who are to perform tests verifying the presence or absence of the material or substance or who are to perform the task of removal or safe containment of the material or substance. The Contractor, the Construction Manager and the Architect will promptly reply to the Owner in writing stating whether or not any of them has reasonable objection to the persons or entities proposed by the Owner. If the Contractor, Construction Manager or Architect has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Contractor, the Construction Manager and the Architect have no reasonable objection. When the material or substance has been rendered harmless, Work in the affected area shall resume. (Paragraph deleted) § 10.3.4 The Owner shall not be responsible under this Section 10.3 for hazardous materials or substances the Contractor brings to the site unless such materials or substances are required by the Contract Documents. The Owner shall be responsible for hazardous materials or substances required by the Contract Documents, except to the extent of the Contractor’s fault or negligence in the use and handling of such materials or substances. § 10.3.5 The Contractor shall reimburse the Owner for the cost and expense the Owner incurs (1) for remediation of hazardous materials or substances the Contractor brings to the site and negligently handles, or (2) where the Contractor fails to perform its obligations under Section 10.3.1, except to the extent that the cost and expense are due to the Owner’s fault or negligence. § 10.3.6 If, without negligence on the part of the Contractor, the Contractor is held liable by a government agency for the cost of remediation of a hazardous material or substance solely by reason of performing Work as required by the Contract Documents, the Owner shall reimburse the Contractor for all cost and expense thereby incurred. § 10.4 Emergencies In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor’s discretion, to prevent threatened damage, injury, or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Article 15 and Article 7. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 30 ARTICLE 11 INSURANCE AND BONDS § 11.1 Contractor’s Insurance and Bonds § 11.1.1 The Contractor shall purchase and maintain insurance of the types and limits of liability, containing the endorsements, and subject to the terms and conditions, as described in the Agreement or elsewhere in the Contract Documents. The Contractor shall purchase and maintain the required insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. The Owner, Construction Manager and Construction Manager’s consultants, and the Architect and Architect’s consultants, shall be named as additional insureds under the Contractor’s commercial general liability policy or as otherwise described in the Contract Documents. § 11.1.2 The Contractor shall provide surety bonds of the types, for such penal sums, and subject to such terms and conditions as required by the Contract Documents. The Contractor shall purchase and maintain the required bonds from a company or companies lawfully authorized to issue surety bonds in the jurisdiction where the Project is located. § 11.1.3 Upon the request of any person or entity appearing to be a potential beneficiary of bonds covering payment of obligations arising under the Contract, the Contractor shall promptly furnish a copy of the bonds or shall authorize a copy to be furnished. § 11.1.4 Notice of Cancellation or Expiration of Contractor’s Required Insurance. Within three (3) business days of the date the Contractor becomes aware of an impending or actual cancellation or expiration of any insurance required by the Contract Documents, the Contractor shall provide notice directly to the Owner, and separately to the Construction Manager, of such impending or actual cancellation or expiration. Upon receipt of notice from the Contractor, the Owner shall, unless the lapse in coverage arises from an act or omission of the Owner, have the right to stop the Work until the lapse in coverage has been cured by the procurement of replacement coverage by the Contractor. The furnishing of notice by the Contractor shall not relieve the Contractor of any contractual obligation to provide any required coverage. § 11.2 Owner’s Insurance § 11.2.1 § 11.2.1 The Owner will purchase and maintain Builder’s Risk Insurance on this project. The Owner shall purchase and maintain the required insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. § 11.2.2 Failure to Purchase Required Property Insurance. If the Owner fails to purchase and maintain the required property insurance, with all of the coverages and in the amounts described in the Agreement or elsewhere in the Contract Documents, the Owner shall inform both the Contractor and the Construction Manager, separately and in writing, prior to commencement of the Work. § 11.2.3 Notice of Cancellation or Expiration of Owner’s Required Property Insurance. Within three (3) business days of the date the Owner becomes aware of an impending or actual cancellation or expiration of any property insurance required by the Contract Documents, the Owner shall provide notice directly to the Contractor, and separately to the Construction Manager, of such impending or actual cancellation or expiration. Unless the lapse in coverage arises from an act or omission of the Contractor: (1) the Contractor, upon receipt of notice from the Owner, shall have the right to stop the Work until the lapse in coverage has been cured by the procurement of replacement coverage by either the Owner or the Contractor. The furnishing of notice by the Owner shall not relieve the Owner of any contractual obligation to provide required insurance. § 11.3 Waivers of Subrogation § 11.3.1 The Contractor waives all rights against (1) the Owner and any of its subcontractors, sub-subcontractors, agents, and employees; (2) the Construction Manager and Construction Manager’s consultants; (3) the Architect and Architect’s consultants; (4) other Contractors and any of their subcontractors, sub-subcontractors, agents, and employees; and (5) Separate Contractors, if any, and any of their subcontractors, sub-subcontractors, agents, and employees, for damages caused by fire, or other causes of loss, to the extent those losses are covered by property insurance required by the Agreement or other property insurance applicable to the Project, including such rights as they have to proceeds of such insurance. The Contractor, shall require similar written waivers in favor of the individuals and entities identified above from the other Contractors, Separate Contractors, subcontractors, and sub-subcontractors. The policies of insurance purchased and maintained by each person or entity agreeing to waive Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 31 claims pursuant to this Section 11.3.1 shall not prohibit this waiver of subrogation. This waiver of subrogation shall be effective as to a person or entity (1) even though that person or entity would otherwise have a duty of indemnification, contractual or otherwise, (2) even though that person or entity did not pay the insurance premium directly or indirectly, or (3) whether or not the person or entity had an insurable interest in the damaged property. (Paragraph deleted) § 11.4 Loss of Use, Business Interruption, and Delay in Completion Insurance (Paragraph deleted) § 11.5 Adjustment and Settlement of Insured Loss (Paragraphs deleted) § ARTICLE 12 UNCOVERING AND CORRECTION OF WORK § 12.1 Uncovering of Work § 12.1.1 If a portion of the Work is covered contrary to the Construction Manager’s or Architect’s request or to requirements specifically expressed in the Contract Documents, it must, if requested in writing by either, be uncovered for their examination and be replaced at the Contractor’s expense without change in the Contract Time. § 12.1.2 If a portion of the Work has been covered that the Construction Manager or Architect has not specifically requested to examine prior to its being covered, the Construction Manager or Architect may request to see such Work and it shall be uncovered by the Contractor. If such Work is in accordance with the Contract Documents, the Contractor shall be entitled to an equitable adjustment to the Contract Sum and Contract Time as may be appropriate. If such Work is not in accordance with the Contract Documents, the costs of uncovering the Work, and the cost of correction, shall be at the Contractor’s expense. § 12.2 Correction of Work § 12.2.1 Before Substantial Completion The Contractor shall promptly correct Work rejected by the Construction Manager or Architect or failing to conform to the requirements of the Contract Documents, discovered before Substantial Completion, and whether or not fabricated, installed or completed. Costs of correcting such rejected Work, including additional testing and inspections, the cost of uncovering and replacement, and compensation for the Construction Manager’s and Architect’s services and expenses made necessary thereby, shall be at the Contractor’s expense. § 12.2.2 After Substantial Completion § 12.2.2.1 In addition to the Contractor’s obligations under Section 3.5, if, within one year after the date of Final Completion of the Work or designated portion thereof, or after the date for commencement of warranties established under Section 9.9.1, or by terms of any applicable special warranty required by the Contract Documents,the period of the required maintenance bond, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. If the Contractor fails to correct nonconforming Work within a reasonable time during that period after receipt of notice from the Owner, Construction Manager or Architect, the Owner may correct it in accordance with Section 2.5. Where the Contractor corrects defective work during the initial one (1) year period after Final Completion, if the Owner discovers defects in the corrected work within one (1) year after the repairs are made, then the Contractor shall be obligated, upon written notice from the Owner, to correct such defects within one (1) year from the date that repairs were made. § 12.2.2.2 The one-year period for correction of Work shall be extended with respect to portions of Work first performed after Substantial Completion by the period of time between Substantial Completion and the actual completion of that portion of the Work. (Paragraph deleted) § 12.2.3 The Contractor shall remove from the site portions of the Work that are not in accordance with the requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 32 § 12.2.4 The Contractor shall bear the cost of correcting destroyed or damaged construction of the Owner, Separate Contractors, or other Contractors, whether completed or partially completed, caused by the Contractor’s correction or removal of Work that is not in accordance with the requirements of the Contract Documents. § 12.2.5 Nothing contained in this Section 12.2 shall be construed to establish a period of limitation with respect to other obligations the Contractor has under the Contract Documents. Establishment of the one-year period for correction of Work as described in Section 12.2.2 relates only to the specific obligation of the Contractor to correct the Work, and has no relationship to the time within which the obligation to comply with the Contract Documents may be sought to be enforced, nor to the time within which proceedings may be commenced to establish the Contractor’s liability with respect to the Contractor’s obligations other than specifically to correct the Work. § 12.2.6 If the Contractor fails or refuses to correct the Work in accordance with its obligations under the Contract Documents after written notice from the Owner, then the Owner may correct the Work and the Contractor shall be liable for the costs to correct the Work, any related architectural, engineering or other consulting costs, attorney’s fees and expenses, and fines or penalties, if any. Any amounts due to the Owner from the Contractor under this Section may be withheld from the balance of the Contract Sum not yet paid. § 12.3 Acceptance of Nonconforming Work If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made. ARTICLE 13 MISCELLANEOUS PROVISIONS § 13.1 Governing Law The Contract shall be governed by the laws of the State of Iowa. § 13.1.1 The Contractor agrees that it will comply with all applicable Federal, State, and local laws, statutes, codes, rules, and regulations having jurisdiction over the Project, including Owner policies. Contractor shall take all necessary precautions to keep the site and work in compliance with the safety and health regulations for construction issued by the Bureau of Labor Standards of the U.S. Department of Labor as well as the Occupational Safety and Health Standards, as amended and as enforced by the State of Iowa § 13.2 Successors and Assigns § 13.2.1 The Owner and Contractor respectively bind themselves, their partners, successors, assigns, and legal representatives to covenants, agreements, and obligations contained in the Contract Documents. Except as provided in Section 13.2.2, neither party to the Contract shall assign the Contract as a whole without written consent of the other. If either party attempts to make an assignment without such consent, that party shall nevertheless remain legally responsible for all obligations under the Contract. § 13.2.2 The Owner may, without consent of the Contractor, assign the Contract to a lender providing construction financing for the Project, if the lender assumes the Owner’s rights and obligations under the Contract Documents. The Contractor shall execute all consents reasonably required to facilitate the assignment. § 13.3 Rights and Remedies § 13.3.1 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties, obligations, rights, and remedies otherwise imposed or available by law. § 13.3.2 No action or failure to act by the Owner, Construction Manager, Architect, or Contractor shall constitute a waiver of a right or duty afforded them under the Contract, nor shall such action or failure to act constitute approval of or acquiescence in a breach thereunder, except as may be specifically agreed upon in writing. § 13.3.2.1 The Owner shall not be precluded or estopped by any measurement, estimate, or certificate made either before or after the completion and acceptance of the work and payment therefore, from showing the true amount and character of the work performed and the materials furnished by the Contractor, or from showing that Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 33 any such measurement, estimate, or certificate is untrue or incorrectly made, or from showing that the work or materials do not in fact conform to the contract documents. § 13.3.2.2 The Owner shall not be precluded or estopped, notwithstanding any such measurement, estimate, or certificate and payment in accordance therewith, from recovering from the Contractor and its Surety such damages as it may sustain, and all outlay and expense it incurs, by reason of the Contractor’s failure to comply with the terms of the Contract. Neither the acceptance by the Owner nor any of its representatives, nor any payment for acceptance of the whole or any part of the work, nor any extension of time, nor any possession taken by the Owner, shall operate as a waiver of any portion of the contract, or any powers herein reserved, or any right to damages herein provided. A waiver of any breach of the contract shall not be held to be a waiver of any other subsequent breach. §13.3.2.3 The Contractor hereby waives any claims it may hereafter be entitled to assert against the Owner, its officers, agents, employees, or consultants, on its behalf or on behalf of its employees, agents, subcontractors, sub-subcontractors, and suppliers, for loss of or damage to personal property, tools, or equipment owned by it or its employees, agents, subcontractors, sub-subcontractors, and suppliers, which loss or damage is sustained on the Owner’s project property, or which occurs during work on the project, and the Contractor agrees to assume liability or responsibility for such claims and to procure insurance to cover its exposure in that regard § 13.4 Tests and Inspections § 13.4.1 Tests, inspections, and approvals of portions of the Work shall be made as required by the Contract Documents and by applicable laws, statutes, ordinances, codes, rules, and regulations or lawful orders of public authorities. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections, and approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall bear all related costs of tests, inspections, and approvals. The Contractor shall give the Construction Manager and Architect timely notice of when and where tests and inspections are to be made so that the Construction Manager and Architect may be present for such procedures. § 13.4.2 If the Construction Manager, Architect, Owner, or public authorities having jurisdiction determine that portions of the Work require additional testing, inspection, or approval not included under Section 13.4.1, the Construction Manager and Architect will, upon written authorization from the Owner, instruct the Contractor to make arrangements for such additional testing, inspection, or approval, by an entity acceptable to the Owner, and the Contractor shall give timely notice to the Construction Manager and Architect of when and where tests and inspections are to be made so that the Construction Manager and Architect may be present for such procedures. Such costs, except as provided in Section 13.4.3, shall be at the Owner’s expense. § 13.4.3 If procedures for testing, inspection, or approval under Sections 13.4.1 and 13.4.2 reveal failure of the portions of the Work to comply with requirements established by the Contract Documents, all costs made necessary by such failure, including those of repeated procedures and compensation for the Construction Manager’s and Architect’s services and expenses, shall be at the Contractor’s expense. § 13.4.4 Required certificates of testing, inspection, or approval shall, unless otherwise required by the Contract Documents, be secured by the Contractor and promptly delivered to the Construction Manager for transmittal to the Architect. § 13.4.5 If the Construction Manager or Architect is to observe tests, inspections, or approvals required by the Contract Documents, the Construction Manager or Architect will do so promptly and, where practicable, at the normal place of testing. § 13.4.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work. § 13.5 Interest Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at the rate the parties agree upon in writing or, in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. § 13.6 Rebates Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 34 § 13.6.1 Owner shall have the right to apply for, and secure all rebates which are available when Bids are received. Contractor shall provide invoices, itemizations, and cooperation to the Owner in this regard. § 13.7 Liquidated Damages § 13.7.1 Time is of the essence of the contract. As delay in the diligent prosecution of the work may inconvenience the public, obstruct traffic, interfere with business, and/or increase costs to the Owner such as engineering, administration, and inspection, it is important the work be prosecuted vigorously to completion. Should the Contractor, or in case of default the surety, fail to complete the work within the contract time plus such extensions of time as may be allowed by the Owner, a deduction at the liquidated damages rate specified in the contract will be made for each and every calendar day or working day, whichever is specified, that such contract remains uncompleted after expiration of the contract time. In either event, the Contractor or the Contractor’s surety shall be responsible for all costs incident to the completion of the work, and shall be required to pay to the Owner liquidated damages stipulated in the Contract. § 13.7.2 The liquidated damages rate specified in the Contract Documents is hereby agreed upon as the true and actual damages due the Owner for loss to the Owner and to the public due to obstruction of traffic, interference with business, and/or increased costs to the Owner such as engineering, administration, and inspection after the expiration of the contract time, or extension thereof. Such liquidated damages may be deducted from any money due or to become due the Contractor under the contract, and the Contractor and its surety shall be liable for any liquidated damages in excess of the amount due the Contractor. § 13.7.3 . Allowing the Contractor to continue and finish the work, or any part of it, after the expiration of the contract time or extension thereof shall in no way operate as a waiver on the part of the Owner of any of its rights or remedies under the contract, including its right to liquidated damages pursuant to this provision. ARTICLE 14 TERMINATION OR SUSPENSION OF THE CONTRACT § 14.1 Termination by the Contractor (Paragraphs deleted) § 14.1.1 The Contractor has no right to stop Work as a consequence of non-payment. In the event of any disagreement between the Contractor and Owner involving the Contractor’s entitlement to payment, the Contractor’s only remedy is to file a Claim in accordance with Article 15. The Contractor must diligently proceed with the Work pending resolution of the Claim. If, however, an Application for Payment has been approved for payment by the Owner, and the Owner fails to make payment within sixty (60) days of the approval for payment by the Owner, the Contractor may upon ten (10) days written notice to the Owner, stop work if payment is not made by the Owner within ten (10) days following the notice. § 14.2 Termination by the Owner for Cause § 14.2.1 The Owner may terminate the Contract if the Contractor .1 Fails to supply adequate properly skilled workers, proper equipment or proper materials; .2 Fails to make payment to Subcontractors or suppliers for material or labor in accordance with the respective agreements between the Contractor and the Subcontractors or suppliers; .3 Fails to comply with any laws, ordinances, or rules, regulations or orders of a public authority having jurisdiction over the Project; .4 Fails to perform the Work in accordance with the Contract Documents or otherwise breaches any provision of the Contract Documents; .5 Anticipatorily breaches or repudiates the Contract; .6 Fails to make satisfactory progress in the prosecution of the Work required by the Contract; or .7 Endangers the performance of this Contract; .8 Fails to carry on the Work in an acceptable manner; Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 35 .9 Fails or refuses to remove and correct rejected, defective, unacceptable or nonconforming work or materials; .10 Disregard of laws, ordinances, or instructions of the Architect or Owner. § 14.2.2 When any of the reasons described in Section 14.2.1 exist, after consultation with the Construction Manager, and upon certification by the Architect that sufficient cause exists to justify such action, the Owner may, without prejudice to any other rights or remedies of the Owner and after giving the (Paragraphs deleted) Contractorseven days’ notice of default, terminate employment of the Contractor. If the default is not cured, the termination for default is effective on the date specified in the Owner’s written notice. However, if the Owner determines that default contributes to the curtailment of an essential service or poses an immediate threat to life, health, or property, the Owner may terminate the Contract immediately upon issuing oral or written notice to the Contractor without any prior notice or opportunity to cure. In addition to any other remedies provided by law or the Contract, the Contractor must compensate the Owner for additional costs that foreseeably would be incurred by the Owner, whether the costs are actually incurred or not, to obtain substitute performance. A termination for default is a termination for convenience if the termination for default is later found to be without justification. (Paragraphs deleted) § 14.2.3 Upon receipt of written notice from the Owner of termination, the Contractor must: .1 Cease operations as directed by the Owner in the notice and, if required by the Owner, participate in an inspection of the Work with the Owner, and the Architect to record the extent of completion thereof, to identify the Work remaining to be completed or corrected, and to determine what temporary facilities, tools, equipment and construction machinery are to remain at the Site pending completion of the Work; .2 Complete or correct the items directed by the Owner, and take actions necessary, or that the Owner may direct, for the protection and preservation of any stored materials and equipment and completed Work; .3 Unless otherwise directed by the Owner, remove its tools, equipment and construction machinery from the Site, and .4 Except as directed by the Owner, terminate all existing subcontracts and purchase orders and enter into no further subcontracts or purchase orders. § 14.2.4 Following written notice from the Owner of termination, the Owner may: .1 Take possession of the Site and of all materials and equipment thereon, and at the Owner’s option, such temporary facilities, tools, construction equipment and machinery thereon owned or rented by the Contractor that the Owner elects to utilize in completing the Work; .2 Accept assignment of subcontracts pursuant to section 5.4 and purchase orders, and/or .3 Complete the Work by whatever reasonable method the Owner may deem expedient. § 14.2.5 Upon termination for cause, Contractor shall take those actions described in Section 14.2.3, and Owner may take those actions described in Section 14.2.4, subject to prior rights of Contractor’s Surety, as applicable. § 14.2.6 When the Owner terminates the Contract for one of the reasons stated in Section 14.2.1, the Contractor shall not be entitled to receive further payment until the Work is finished. § 14.2.7 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including actual or Liquidated Damages,compensation for the Construction Manager’s and Architect’s services and expenses made necessary thereby, and other damages incurred by the Owner and not expressly waived, such excess shall be paid to the Contractor. If such costs and damages exceed the unpaid balance, the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case may be, shall, upon application, be certified by the Initial Decision Maker after consultation with the Construction Manager, and this obligation for payment shall survive termination of the Contract. § 14.2.8 If the Contractor files for protection, or a petition is filed against it, under the Bankruptcy laws, the Contractor wishes to affirm the Contract, Contractor shall immediately file with the Bankruptcy Court a motion to affirm the Contract and shall provide satisfactory evidence to Owner and to the Court of its ability to cure all present defaults and its ability to timely and successfully complete the Work. If Contractor does not make such an immediate Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 36 filing, Contractor accepts that Owner shall petition the Bankruptcy Court to lift the Automatic Stay and permit Owner to terminate the Contract. § 14.3 Suspension by the Owner for Convenience § 14.3.1 The Owner may, without cause, order the Contractor in writing to suspend, delay or interrupt the Work, in whole or in part for such period of time as the Owner may determine. § 14.3.2 The Contract Sum and the Contract Time shall be adjusted for increases in the cost and time caused by suspension, delay, or interruption under Section 14.3.1. Adjustment of the Contract Sum shall include profit. No adjustment shall be made to the extent: .1 that performance is, was, or would have been, so suspended, delayed, or interrupted, by another cause for which the Contractor is responsible; or .2 that an equitable adjustment is made or denied under another provision of this Contract. § 14.4 Termination by the Owner for Convenience § 14.4.1 The Owner may, at any time, terminate the Contract for the Owner’s convenience and without cause. § 14.4.2 Upon receipt of notice from the Owner of such termination for the Owner’s convenience, the Contractor shall .1 cease operations as directed by the Owner in the notice; .2 take actions necessary, or that the Owner may direct, for the protection and preservation of the Work; and .3 except for Work directed to be performed prior to the effective date of termination stated in the notice, terminate all existing subcontracts and purchase orders and enter into no further subcontracts and purchase orders. § 14.4.3 In case of termination for the Owner’s convenience, the Contractor will be entitled to compensation only for the following items: .1 Payment for acceptable Work performed up to the date of termination; .2 The costs of preservation and protection of the Work if requested to do so by the Owner; .3 The cost of terminating the following contracts. including: a. Purchased materials but only if not returnable and provided to the Owner, or the restocking or return charge, if any, if returnable at the Owner’s written election; b. Equipment rental contracts if not terminable at no cost but not to exceed an amount equal to thirty (30) days rental; c. Documented transportation costs associated with removing Contractor-owned equipment; d. Documented demobilization and close-out costs; and e. Overhead and profit on the foregoing not to exceed ten percent (10%). The Contractor will not be compensated for the cost of any idled employees unless the employee is under a written employment contract entitling the employee to continued employment after termination of the Contract and the employee cannot be assigned to other work provided that in all events the Contractor’s costs must be limited to thirty (30) days of employment costs from the date of the notice of termination. The Contractor is not entitled to any other costs or compensation (including lost or expected profit, uncompensated overhead or related expenses, or the cost of preparing and documenting its compensable expenses under this Section 14.4.4 as a consequence of the Owner’s termination of the Contract for convenience. The Contractor conclusively and irrevocably waives its right to any other compensation or damages (compensatory or punitive) arising from termination of the Contract. If the Owner and the Contractor are unable to agree upon the amounts specified in this subsection, the Contractor may submit a Claim as provided in Article 15. The Claim must be limited to resolution of the amounts specified in Subsections 14.4.4.1, 14.4.4.2, and 14.4.4.3 of this Subsection 14.4.4. No other cost, damages or expenses may be claimed or paid to the Contractor or considered as part of the Claim, the same being hereby conclusively and irrevocably waived by the Contractor. Any such Claim must be delivered to the Owner within thirty (30) days of the termination of the Contract and must contain a written statement setting forth the specific reasons and supporting calculations and documentation as to the amounts the Contractor claims to be entitled to under this Subsection as a result of the termination of the Contract. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 37 § 14.4.4 The Contractor’s obligations surviving final payment under the Contract, including without limitation those with respect to insurance, indemnification, and correction of Work that has been completed at the time of termination, remains effective notwithstanding termination for convenience of the Owner. ARTICLE 15 CLAIMS AND DISPUTES § 15.1 Claims § 15.1.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of right, payment of money, a change in the Contract Time, or other relief with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and Contractor arising out of or relating to the Contract. The responsibility to substantiate Claims shall rest with the party making the Claim. This Section 15.1.1 does not require the Owner to file a Claim in order to impose liquidated damages in accordance with the Contract Documents. § 15.1.2 Time Limits on Claims The Owner and Contractor shall commence all Claims and causes of action against the other and arising out of or related to the Contract, whether in contract, tort, breach of warranty or otherwise, in accordance with the requirements of the binding dispute resolution method selected in the Agreement and within the period specified by applicable law, but in any case not more than 10 years after the date of Final Acceptance of the Work by Owner. The Owner and Contractor waive all Claims and causes of action not commenced in accordance with this Section 15.1.2. § 15.1.3 Notice of Claims § 15.1.3.1 Claims by either the Owner or Contractor, where the condition giving rise to the Claim is first discovered prior to expiration of the period for correction of the Work set forth in Section 12.2.2, shall be initiated by notice to the other party and to the Initial Decision Maker with a copy sent to the Construction Manager and Architect, if the Architect is not serving as the Initial Decision Maker. Claims by either party under this Section 15.1.3.1 shall be initiated within a reasonable time after the occurrence of the event giving rise to such Claim or within a reasonable time after the claimant first recognizes the condition giving rise to the Claim, whichever is later. § 15.1.3.2 Claims by either the Owner or Contractor, where the condition giving rise to the Claim is first discovered after expiration of the period for correction of the Work set forth in Section 12.2.2, shall be initiated by notice to the other party. In such event, no decision by the Initial Decision Maker is required. § 15.1.4 Continuing Contract Performance § 15.1.4.1 Pending final resolution of a Claim, except as otherwise agreed in writing or as provided in Section 9.7 and Article 14, the Contractor shall proceed diligently with performance of the Contract and the Owner shall continue to make payments in accordance with the Contract Documents. § 15.1.4.2 The Contract Sum and Contract Time shall be adjusted in accordance with the Initial Decision Maker’s decision, subject to the right of either party to proceed in accordance with this Article 15. The Architect will issue Certificates for Payment in accordance with the decision of the Initial Decision Maker. § 15.1.5 Claims for Additional Cost. If the Contractor wishes to make a Claim for an increase in the Contract Sum, notice as provided in Section 15.1.3 shall be given before proceeding to execute the portion of the Work that is the subject of the Claim. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Section 10.4. § 15.1.6 Claims for Additional Time § 15.1.6.1 If the Contractor wishes to make a Claim for an increase in the Contract Time, notice as provided in Section 15.1.3 shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay only one Claim is necessary. § 15.1.6.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time, could not have been reasonably anticipated and had an adverse effect on the scheduled construction. Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 38 § 15.1.7 Waiver of Claims for Consequential Damages. The Contractor waives Claims against the Owner for consequential damages arising out of or relating to this Contract. This waiver includes .1 damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed there, for losses of financing, business and reputation, and for loss of profit.. This waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14. Nothing contained in this Section 15.1.7 shall be deemed to preclude assessment of liquidated damages, when applicable, in accordance with the requirements of the Contract Documents. § 15.2 Initial Decision § 15.2.1 Claims, excluding those where the condition giving rise to the Claim is first discovered after expiration of the period for correction of the Work set forth in Section 12.2.2 or arising under Sections 10.3, 10.4, and 11.5, shall be referred to the Initial Decision Maker for initial decision. The Architect will serve as the Initial Decision Maker, unless otherwise indicated in the Agreement. Except for those Claims excluded by this Section 15.2.1, an initial decision shall be required as a condition precedent to mediation of any Claim. If an initial decision has not been rendered within 30 days after the Claim has been referred to the Initial Decision Maker, the party asserting the Claim may request mediation and binding dispute resolution without a decision having been rendered to the extent provided in this agreement. Unless the Initial Decision Maker and all affected parties agree, the Initial Decision Maker will not decide disputes between the Contractor and persons or entities other than the Owner. § 15.2.2 The Initial Decision Maker will review Claims and within ten days of the receipt of a Claim take one or more of the following actions: (1) request additional supporting data from the claimant or a response with supporting data from the other party, (2) reject the Claim in whole or in part, (3) approve the Claim, (4) suggest a compromise, or (5) advise the parties that the Initial Decision Maker is unable to resolve the Claim if the Initial Decision Maker lacks sufficient information to evaluate the merits of the Claim or if the Initial Decision Maker concludes that, in the Initial Decision Maker’s sole discretion, it would be inappropriate for the Initial Decision Maker to resolve the Claim. § 15.2.3 In evaluating Claims, the Initial Decision Maker may, but shall not be obligated to, consult with or seek information from either party or from persons with special knowledge or expertise who may assist the Initial Decision Maker in rendering a decision. The Initial Decision Maker may request the Owner to authorize retention of such persons at the Owner’s expense. § 15.2.4 If the Initial Decision Maker requests a party to provide a response to a Claim or to furnish additional supporting data, such party shall respond, within ten days after receipt of the request, and shall either (1) provide a response on the requested supporting data, (2) advise the Initial Decision Maker when the response or supporting data will be furnished, or (3) advise the Initial Decision Maker that no supporting data will be furnished. Upon receipt of the response or supporting data, if any, the Initial Decision Maker will either reject or approve the Claim in whole or in part. § 15.2.5 The Initial Decision Maker will render an initial decision approving or rejecting the Claim, or indicating that the Initial Decision Maker is unable to resolve the Claim. This initial decision shall (1) be in writing; (2) state the reasons therefor; and (3) notify the parties, the Construction Manager, and the Architect, if the Architect is not serving as the Initial Decision Maker, of any change in the Contract Sum or Contract Time or both. The initial decision shall be final and binding on the parties but subject to mediation and, if the parties fail to resolve their dispute through mediation, to binding dispute resolution. § 15.2.6 The parties may participate in mediation of an initial decision at any time, upon mutual agreement of the parties. (Paragraph deleted) § 15.2.7 In the event of a Claim against the Contractor, the Owner may, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim. If the Claim relates to a possibility of a Contractor’s default, the Owner may, but is not obligated to, notify the surety and request the surety’s assistance in resolving the controversy. (Paragraph deleted) Init. / AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 39 § 15.3 Mediation § 15.3.1 Not Applicable (Paragraphs deleted) § 15.3.2 The parties shall endeavor in good faith to resolve claims, disputes and other matters in question between them by mutual agreement and may, by mutual agreement and in their discretion, submit same to non-binding mediation which shall be in accordance with Iowa Code Chapter 679C, unless otherwise mutually agreed by the parties. Requests for mediation shall be given in writing to the other party to this Agreement. If the Owner and Contractor are unable to mutually agree upon a mediator in writing within sixty (60) days of receiving the written request for mediation, either party may then institute legal or equitable proceedings. Mediation shall be voluntary only and shall not be a prerequisite to litigation or other means of dispute resolution. § 15.3.4 The parties shall share the mediator’s fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof. (Paragraphs deleted) Additions and Deletions Report for AIA® Document A232® – 2019 This Additions and Deletions Report, as defined on page 1 of the associated document, reproduces below all text the author has added to the standard form AIA document in order to complete it, as well as any text the author may have added to or deleted from the original AIA text. Added text is shown underlined. Deleted text is indicated with a horizontal line through the original AIA text. Note: This Additions and Deletions Report is provided for information purposes only and is not incorporated into or constitute any part of the associated AIA document. This Additions and Deletions Report and its associated document were generated simultaneously by AIA software at 10:58:13 ET on 01/15/2026. Additions and Deletions Report for AIA Document A232 – 2019. Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 1 PAGE 1 Waukee Existing Fire/Police Building Renovation 1300 SE La Grant Parkway, Waukee, Iowa 50263 … Ryan Companies, US Inc. 111 E Grand Avenue, Suite 200 Des Moines, IA 50309 … City of Waukee Iowa 230 W Hickman Road Waukee, IA 50263 … OPN Architects 100 Court Avenue, #100 Des Moines, IA 50309 PAGE 4 § 1.2.1 The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by the Contractor. Contractor and to require the furnishing of the highest quality equipment, material, and workmanship, and best accepted construction practices The Contract Documents are complementary, and what is required by one shall be as binding as if required by all; performance by the Contractor shall be required only to the extent consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the indicated results. … § 1.5.1 The Without waiving or otherwise altering the license granted in the contracts between Owner and Architect and Architect’s consultants, the Architect and the Architect’s consultants shall be deemed the authors and owners of their respective Instruments of Service, including the Drawings and Specifications, and retain all common law, statutory, and other reserved rights in their Instruments of Service, including copyrights. The Contractor, Subcontractors, sub-subcontractors, and suppliers shall not own or claim a copyright in the Instruments of Service. Submittal or distribution to meet official regulatory requirements or for other purposes in connection with the Project is not to be construed as publication in derogation of the Architect’s or Architect’s consultants’ reserved rights. § 1.5.2 The Without waiving or otherwise altering the license granted in the contracts between Owner and Architect and Architect’s consultants, the Contractor, Subcontractors, Sub-subcontractors, and suppliers are authorized to use and reproduce the Instruments of Service provided to them, subject to any protocols established pursuant to Sections 1.7 and 1.8, solely and exclusively for execution of the Work. All copies made under this authorization shall bear the copyright notice, if any, shown on the Instruments of Service. The Contractor, Subcontractors, Sub-subcontractors, Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 2 and suppliers may not use the Instruments of Service on other projects or for additions to the Project outside the scope of the Work without the specific written consent of the Owner, Architect, and the Architect’s consultants. PAGE 5 The parties shall agree upon written protocols governing the transmission and use of, and reliance on, of Instruments of Service or any other information or documentation in digital form. The parties will use AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, to establish the protocols for the development, use, transmission, and exchange of digital data. … Any use of, or reliance on, all or a portion of a building information model without agreement to written protocols governing the use of, and reliance on, the information contained in the model and without having those protocols set forth in AIA Document E203™–2013, Building Information Modeling and Digital Data Exhibit, and the requisite AIA Document G202™–2013, Project Building Information Modeling Protocol Form, shall be at the using or relying party’s sole risk and without liability to the other party and its contractors or consultants, the authors of, or contributors to, the building information model, and each of their agents and employees. … § 2.1.2 The Owner shall furnish to the Contractor, within fifteen days after receipt of a written request, information necessary and relevant for the Contractor to evaluate, give notice of, or enforce mechanic’s lien rights. Such information shall include a correct statement of the record legal title to the property on which the Project is located, usually referred to as the site, and the Owner’s interest therein. § 2.2 Evidence of the Owner’s Financial Arrangements § 2.2.1 Prior to commencement of the Work, and upon written request by the Contractor, the Owner shall furnish to the Contractor reasonable evidence that the Owner has made financial arrangements to fulfill the Owner’s obligations under the Contract. The Contractor shall have no obligation to commence the Work until the Owner provides such evidence. If commencement of the Work is delayed under this Section 2.2.1, the Contract Time shall be extended appropriately. § 2.2.2 Following commencement of the Work and upon written request by the Contractor, the Owner shall furnish to the Contractor reasonable evidence that the Owner has made financial arrangements to fulfill the Owner’s obligations under the Contract only if (1) the Owner fails to make payments to the Contractor as the Contract Documents require; (2) the Contractor identifies in writing a reasonable concern regarding the Owner’s ability to make payment when due; or (3) a change in the Work materially changes the Contract Sum. If the Owner fails to provide such evidence, as required, within fourteen days of the Contractor’s request, the Contractor may immediately stop the Work and, in that event, shall notify the Owner that the Work has stopped. However, if the request is made because a change in the Work materially changes the Contract Sum under (3) above, the Contractor may immediately stop only that portion of the Work affected by the change until reasonable evidence is provided. If the Work is stopped under this Section 2.2.2, the Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor’s reasonable costs of shutdown, delay and start-up, plus interest as provided in the Contract Documents. § 2.2.3 After the Owner furnishes evidence of financial arrangements under this Section 2.2, the Owner shall not materially vary such financial arrangements without prior notice to the Contractor. § 2.2.4 Where the Owner has designated information furnished under this Section 2.2 as "confidential," the Contractor shall keep the information confidential and shall not disclose it to any other person. However, the Contractor may disclose "confidential" information, after seven (7) days’ notice to the Owner, where disclosure is required by law, including a subpoena or other form of compulsory legal process issued by a court or governmental entity, or by court or arbitrator(s) order. The Contractor may also disclose "confidential" information to its employees, consultants, sureties, Subcontractors and their employees, Sub-subcontractors, and others who need to know the content of such information solely and exclusively for the Project and who agree to maintain the confidentiality of such information. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 3 § 2.3.1 Except for permits and fees that are the responsibility of the Contractor under the Contract Documents, including those required under Section 3.7.1, the Owner shall secure and pay for necessary approvals, easements, assessments and charges required for construction, use or occupancy of permanent structures or for permanent changes in existing facilities. Unless otherwise provided under the Contract Documents, the Owner, assisted by the Construction Manager, shall secure and pay for the building permit. PAGE 6 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten-day period after receipt of notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such default or neglect. Such action by the Owner and amounts charged to the Contractor are both subject to review by the Construction Manager and prior approval of the Architect, and the Construction Manager or Architect may, pursuant to Section 9.5.1, withhold or nullify a Certificate for Payment in whole or in part, to the extent reasonably necessary to reimburse the Owner for the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Construction Manager’s and Architect’s and their respective consultants’ additional services made necessary by such default, neglect, or failure. If current and future payments are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. If the Contractor disagrees with the actions of the Owner or the Architect, or the amounts claimed as costs to the Owner, the Contractor may file a Claim pursuant to Article 15. … § 3.1.2 The Contractor shall perform the Work in accordance with industry standard and in a excellent and workmanlike manner complete the work and everything properly incidental thereto as stated in the Project Manual and Drawings or reasonably implied therefrom and otherwise in accordance with Contract Documents. In no case shall the Contractor proceed with any portion of the Work in any uncertainty. … § 3.2.1 Execution of the Contract by the Contractor is a representation that the Contractor has visited the site, Project site and has and carefully examined the Site, the Contract Documents, and is fully informed concerning the requirements of the Contract, the physical conditions to be encountered, the quantity of the Work, as well as materials and equipment to be furnished, become generally familiar with local conditions under which the Work is to be performed, and correlated personal observations with requirements of the Contract Documents. The Contractor also represents that all Contract Documents for the Project have been examined; including those intended for work of trades not normally performed by the Contractor’s own forces, and that it has become thoroughly familiar with all conditions which may pertain to or affect the Work under the Contract. PAGE 7 § 3.2.3 The Contractor is not required to ascertain that the Contract Documents are in accordance with applicable laws, statutes, ordinances, codes, rules and regulations, or lawful orders of public authorities, but If the Contractor believes that any portions of the Contract Documents do not comply with applicable laws, statutes, ordinances, building codes, and rules and regulations, or any orders by code enforcement officials or the Owner or its designees acting in the capacity of building code inspectors, the Contractor shall promptly report to the Construction Manager and Architect any nonconformity discovered by or made known to the Contractor as a request for information submitted to Construction Manager in such form as the Construction Manager and Architect may require.require before proceeding with the affected Work. § 3.2.4 If the Contractor believes that additional cost or time is involved because of clarifications or instructions the Architect issues in response to the Contractor’s notices or requests for information pursuant to Sections 3.2.2 or 3.2.3, the Contractor shall submit Claims as provided in Article 15. If the Contractor fails to perform the obligations of Sections 3.2.2 or 3.2.3, the Contractor shall pay such costs and damages to the Owner, subject to section 15.1.7, as would have been avoided if the Contractor had performed such obligations. If the Contractor performs those obligations, the Contractor shall not be liable to the Owner or Architect for damages resulting from errors, inconsistencies or omissions in the Contract Documents, for differences between field measurements or conditions Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 4 and the Contract Documents, or for nonconformities of the Contract Documents to applicable laws, statutes, ordinances, codes, rules and regulations, and lawful orders of public authorities. … § 3.5.1 The Contractor warrants to the Owner, Construction Manager, and Architect that materials and equipment furnished under the Contract will be of good quality and new unless the Contract Documents require or permit otherwise. The Contractor further warrants that the Work will conform to the requirements of the Contract Documents and will be free from defects, except for those inherent in the quality of the Work the Contract Documents require or permit. completed in a good and workman like manner and free from defects,. Work, materials, or equipment not conforming to these requirements may be considered defective. The Contractor’s warranty excludes remedy for damage or defect caused by abuse, alterations to the Work not executed by the Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear and normal usage. If required by the Construction Manager or Architect, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. PAGE 8 The Contractor shall pay sales, required consumer, use and similar taxes for the Work or portions thereof provided by the Contractor that are legally enacted when bids are received or negotiations concluded, whether or not yet effective or merely scheduled to go into effect. However, The Owner is a designated exempt entity and will complete an online application to register this Contract with the Iowa Department of Revenue and Finance. The Owner will distribute Tax Exemption Certificates and Authorization Letters to the Contractor and all Subcontractors who have been identified by Contractor. Refer to Iowa Department of Revenue and Finance publications available at http://www.state.ia.us/tax/business/Contr-ExEnt-Index.html. Contractor shall be responsible for informing themselves of tax laws, requirements, regulations, and interpretations as they apply to this Project. PAGE 9 § 3.10.1 The Contractor, promptly after being awarded the Contract, shall submit for the Owner’s and Architect’s information, and the Construction Manager’s use in developing the Project schedule, a Contractor’s construction schedule for the Work. Work within the time frame provided in the bidding documents date of substanstial completion. The schedule shall contain detail appropriate for the Project, including (1) the date of commencement of the Work, interim schedule milestone dates, and the date of Substantial Completion; (2) an apportionment of the Work by construction activity; and (3) the time required for completion of each portion of the Work. The schedule shall provide for the orderly progression of the Work to completion and shall not exceed time limits current under the Contract Documents. The schedule shall be revised at appropriate intervals as required by the conditions of the Work and Project. The Contractor shall cooperate with the Construction Manager in scheduling and performing the Contractor’s Work to avoid conflict with, and as to cause no delay in, the work or activities of other Contractors, or the construction or operations of the Owner’s own forces or Separate Contractors. PAGE 15 § 4.2.19 Interpretations and decisions of the Architect will be consistent with the intent of, and reasonably inferable from, the Contract Documents and will be in writing or in the form of drawings. When making such interpretations and decisions, the Architect will endeavor to secure faithful performance by both Owner and Contractor, will not show partiality to either, and will not be liable for results of interpretations or decisions so rendered in good faith.either.. PAGE 16 .1 assignment is effective only after termination of the Contract by the Owner for cause pursuant to Section 14.2 pursuant to the Contract and only for those subcontract agreements that the Owner accepts by notifying the Subcontractor and Contractor; and … § 5.4.2 Upon such assignment, if the Work has been suspended for more than 30 days, the Subcontractor’s compensation shall may be equitably adjusted for increases in cost resulting from the suspension.suspension, if any. § 5.4.3 Upon assignment to the Owner under this Section 5.4, the Owner may further assign the subcontract to a successor Contractor or other entity. If the Owner assigns the subcontract to a successor Contractor or other entity, the Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 5 Owner shall nevertheless not remain legally responsible for all of the successor Contractor’s obligations under the subcontract. PAGE 17 § 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the Contract, by Change Order, Construction Change Directive or order for a minor change in the Work, subject to the limitations stated in this Article 7 and elsewhere in the Contract Documents. No claim for an addition to the maximum Contract sum shall be considered a valid claim unless a written change order procedure is followed as outlined in this section. Verbal authorization for changes must be supported by written approval before being considered valid. … § 7.2.2 The Contractor must submit change proposals covering a contemplated Change Order within ten (10) days after request of the Owner, or the Architect or within ten (10) days of the event giving rise to the Contractor’s claim for a change in the Contract Sum or Contract time. No increase in the Contract Sum or extension of the Contract Time will be allowed the Contractor for the cost or time involved in making change proposals. Change proposals will define or confirm in detail the Work which is proposed to be added, deleted, or changed and must include any adjustment which the Contractor believes to be necessary in (i) the Contract Sum, or (ii) the Contract Time. Any proposed adjustment must include detailed documentation including, but not limited to: cost, properly itemized and supported by sufficient substantiating data to permit evaluation including cost of labor, materials, supplies and equipment, rental cost of machinery and equipment, additional bond cost, plus a fixed fee for profit and overhead. § 7.2.3 If the Architect determines that a change proposal is appropriate, the Architect will recommend a request for a Change Order or Contract Amendment providing for an appropriate adjustment in the Contract Sum or Contract Time, or both, for further action by the Owner. The Owner will prepare the Change Order form. No such change is effective until the Owner and Contractor sign the Change Order. § 7.2.4 The form used to process a Change Order will be the form provided by Owner. PAGE 19 § 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, commence the Work prior to the effective date of insurance required to be furnished by the Contractor and Owner.Contractor. § 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. If Contractor’s Work shall fall behind schedule for reasons that are not excused under the terms of the Contract, Contractor shall add additional workers or shifts, and/or work overtime as necessary to maintain the Construction Schedule, solely at the Contractor’s expense. § 8.2.4 The Contractor must conform to the most recently approved Construction Schedule. The Contractor must complete the indicated Work or achieve the required percentage of completion, as applicable, within any interim completion dates established in the most recently approved Construction Schedule. § 8.2.5 Contractor shall maintain at Site, available to Owner and Architect for their reference during progress of Work, a copy of approved Construction Schedule and any approved revisions thereto. Contractor shall keep current records of, and mark on copy of approved Construction Schedule actual commence date, progress, and completion date of each scheduled activity, indicated on Construction Schedule. § 8.2.6 The Contractor represents that its Guaranteed Maximum Price includes all costs, overhead and profit which may be incurred throughout the Contract Time and the period between Substantial and Final Completion. Accordingly, the Contractor may not make any claim for delay damages based in whole or in part on the premise that the Contractor would have completed the Work prior to the expiration of the Contract Time but for any claimed delay. § 8.2.7 If the Contractor’s progress is not maintained in accordance with the approved Construction Schedule, or the Owner determines that the Contractor is not diligently proceeding with the Work or has evidence reasonably indicating that the Contractor will not be able to conform to the most recently approved Construction Schedule, the Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 6 Contractor must, promptly and at no additional cost to the Owner, take all measurers necessary to accelerate its progress to overcome the delay and ensure that there will be no further delay in the progress of the Work and notify the Owner. PAGE 20 § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by (1) an act or neglect of the Owner, Architect, Construction Manager, or an employee of any of them, or of the Owner’s own forces, Separate Contractors, or other Contractors; (2) by changes ordered in the Work; (3) by labor disputes, fire, unusual delay in deliveries, unavoidable casualties, adverse weather conditions documented in accordance with Section 15.1.6.2, or other causes beyond the Contractor’s control; (4) by delay authorized by the Owner pending mediation and binding dispute resolution; or (5) by other causes that the Contractor asserts and the Architect, based on the recommendation of the Construction Manager, determines justify delay, then the Contract Time shall be extended for such reasonable time as the Architect may determine. A time extension shall be Contractor’s sole remedy and compensation for all such delays other than those resulting from the acts or negligence of the Owner, the Architect, or the Owner’s separate contractors (collectively "Owner Caused Delays"). For proven Owner Caused Delays, the Contractor may recoup the actual costs resulting from such delays, but not for any additional profit or fee. § 8.3.2 Claims Permissable claims relating to time shall be made in accordance with applicable provisions of Article 15. § 8.3.3 This Except as otherwise provided, this Section 8.3 does not preclude recovery of damages for delay by either party under other provisions of the Contract Documents. PAGE 22 .7 repeated failure to carry out the Work in accordance with the Contract Documents.Documents; .8 service work not attended to; .9 evidence of lack of careful workmanship; .10 unworkmanlike or over expeditious construction; .11 lack of attention to the special field duties specified. PAGE 23 § 9.6.7 Unless the Contractor provides the Owner with a payment bond in the full penal sum of the Contract Sum, payments received by the Contractor for Work properly performed by Subcontractors or provided by suppliers shall be held by the Contractor for those Subcontractors or suppliers who performed Work or furnished materials, or both, under contract with the Contractor for which payment was made by the Owner. Nothing contained herein shall require money to be placed in a separate account and not commingled with money of the Contractor, create any fiduciary liability or tort liability on the part of the Contractor for breach of trust, or entitle any person or entity to an award of punitive damages against the Contractor for breach of the requirements of this provision. § 9.6.8 Provided the Owner has fulfilled its payment obligations under the Contract Documents, the Contractor shall defend and indemnify the Owner from all loss, liability, damage or expense, including reasonable attorney’s fees and litigation expenses, arising out of any lien Iowa Code Chapter 573 claim or other claim for payment by any Subcontractor or supplier of any tier. Upon receipt of notice of a lien an Iowa Code Chapter 573 claim or other claim for payment, the Owner shall notify the Contractor. If approved by the applicable court, when required, the Contractor may substitute a surety bond for the property against which the lien Iowa Code Chapter 573 or other claim for payment has been asserted. PAGE 24 If Owner does not pay the Contractor within sixty (60) days after the Construction Manager and Architect do not issue a Certificate for Payment or a Project Certificate for Payment, through no fault of the Contractor, within fourteen days after the Construction Manager’s receipt of the Contractor’s Application for Payment, or if the Owner does not pay the Contractor within seven days after the date established in the Contract Documents, the amount certified by the Construction Manager and Architect or awarded by binding dispute resolution, then the Contractor may, upon seven additional days’ notice to the Owner, Construction Manager and Architect, stop the Work until payment of the amount owing has been received. The Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor’s reasonable costs of shutdown, delay and start-up, plus interest as provided for in the Contract Documents. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 7 the Contractor may file a claim in accordance with Article 15 of this Contract. … § 9.8.4 When the Architect, assisted by the Construction Manager, determines that the Work of all of the Contractors, or designated portion thereof, is substantially complete, the Construction Manager will prepare, and the Construction Manager and Architect shall execute, a Certificate of Substantial Completion that shall establish the date of Substantial Completion; establish responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance; and fix the time within which the Contractor shall finish all items on the list accompanying the Certificate. Warranties However, warranties required by the Contract Documents shall commence on the date of Substantial Completion not commence until the date Owner has issued a final acceptance of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion. § 9.8.5 The Certificate of Substantial Completion shall be submitted to the Owner and Contractor for their written acceptance of responsibilities assigned to them in the Certificate. Upon such acceptance, and consent of surety if any, the Owner shall make payment of retainage applying to the Work or designated portion thereof. thereof in the manner provided under applicable Iowa law and this section 9.8. Such payment shall be adjusted for Work that is incomplete or not in accordance with the requirements of the Contract Documents. § 9.8.6 The Certificate of Substantial Completion and accompanying Punch List must be submitted to the Owner and Contractor for execution, which will constitute their written acceptance of responsibilities assigned to them in such Certificate. Contractor must make all corrections on the punch list prior to notifying Architect of its completion as outlined in Section 9.10. The Contractor shall reimburse the Owner for any Architect’s additional services or attorney’s fees incurred as a result of Contractor’s failure to finally complete the Work within sixty (60) days after the date specified in the Contract Documents for Project Substantial Completion, or subsequently modified by Change Orders or dates established in the Certificate of Substantial Completion. Reimbursement for these Additional Services will be deducted by the Owner from the amounts due the Contractor and paid directly to the Architect. For purposes of this paragraph "incurred as a result of" includes any architectural fees charged to Owner as Additional Fees under the contract due to the fact that the services were performed sixty (60) days (or some other amount of time specified in the Owner/Architect Agreement) after Substantial Completion. The nature of the services performed (and whether they would have otherwise been performed as normal closeout services at some point under Basic Services) is not relevant to the Contractor’s obligations for reimbursement under this section if the contract between the Owner and Architect states that any and all services and related fees are defined as Additional Services solely because they were performed more than sixty (60) days (or some other amount of time specified in the Owner/Architect Agreement) after Substantial Completion. § 9.8.7 Request for Early Release of Retainage Funds: Upon achieving Substantial Completion, as defined by Iowa law, the Contractor may formally request the release of all or part of the retainage funds being held on the Project. The Contractors’ request for Release of the Retainage Funds shall be accompanied by a sworn statement that ten (10) calendar days prior to filing the Request for Release of the Funds a notice was given to all known subcontractors, sub-subcontractors and suppliers that the Contractor is requesting the early release of retainage funds. If proper documentation is received from the Contractor, the Owner will release all retainage funds at the next monthly Council meeting or within thirty (30) days, whichever is less, except it may retain the following to the extent authorized by law: a) An amount equal to 200% of the value of labor or materials yet to be provided on the Project as determined by the Owner and its authorized contract representative. For purposes of this section, "authorized contract representative" means the Architect of record on the Project, unless otherwise specified. b) An amount equal to 200% of the value of any Chapter 573 claims currently on file at the time the Request for Release of Retainage is approved. c) An amount equal to one-half percent (½%) of the total value of the Project for Operation, Maintenance and Warranty Manuals and Record Drawings and Specifications not submitted ten (10) days prior to Substantial Completion inspection. If the Owner withholds an amount from the retainage payment to the Contractor, the Owner will provide a reason the request is being denied to the Contractor within thirty (30) calendar days of the receipt of the request. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 8 § 9.8.8 Warranties required by the Contract Documents will commence on the Date of Final Completion of the Work unless otherwise provided in the Certificate of Substantial Completion or the Contract Documents. § 9.8.9 Upon execution of the Certificate of Substantial Completion, the Contractor will deliver custody and control of such Work to the Owner. The Owner will thereafter provide the Contractor reasonable access to such Work to permit the Contractor to fulfill the correction, completion and other responsibilities remaining under the Contract and the Certificate of Substantial Completion. § 9.8.10 Unless otherwise provided in the Certificate of Substantial Completion, the Contractor must complete or correct all items included in the final Punch List within sixty (60) days, subject to the availability of special order parts and materials, after the Date of Substantial Completion. § 9.8.11 At the time of Substantial Completion, in addition to removing rubbish and leaving the building "broom clean," the Contractor must replace any broken or damaged materials, remove stains, spots, marks and dirt from decorated Work, clean all fixtures, vacuum all carpets and wet mop all other floors, replace HVAC filters, clean HVAC coils, and comply with such additional requirements, if any, which may be specified in the Contract Documents. PAGE 26 § 9.10.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by issuance of Change Orders affecting final completion, and the Construction Manager and Architect so confirm, the Owner shall, upon application by the Contractor and certification by the Construction Manager and Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed, corrected, and accepted. If the remaining balance for Work not fully completed or corrected is less than retainage stipulated in the Contract Documents, and if bonds have been furnished, the written consent of the surety to payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect through the Construction Manager prior to certification of such payment. Such payment shall be made under terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. § 9.10.4 The making of final payment shall constitute a waiver of Claims by the Owner except those arising from .1 liens, Claims, security interests, or encumbrances arising out of the Contract and unsettled; .2 failure of the Work to comply with the requirements of the Contract Documents; .3 terms of special warranties required by the Contract Documents; or .4 audits performed by the Owner, if permitted by the Contract Documents, after final payment. § 9.10.3 Final payment will be made no earlier than thirty-one (31) days following approval by the Owner’s City Council at a regularly scheduled meeting, receipt of all Chapter 573 Claim Releases, Sales Tax information, and all other required closeout documents, and subject to the conditions of and in accordance with the provisions of Iowa Code Chapter 573 and Iowa Code Chapter 26. Owner may withhold from final payment any and all amounts required to reimburse the Owner for all costs, fees (including reasonable attorney’s fees) it incurred as a result of any Chapter 573 Claims filed on the Project. Neither final payment nor any remaining retained percentage will become due until the Contractor submits the following documents to the Architect: .1 An Affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner’s property might be responsible or encumbered (less amounts withheld by Owner), have been paid or otherwise satisfied, submitted on AIA Document G706, Affidavit of Payment of Debts and Claims (latest edition) or such other form as may be prescribed by the Owner; .2 A release or waiver of liens and Iowa Code Chapter 573 claims, on behalf of the Contractor and a similar release or waiver on behalf of each Subcontractor and supplier, accompanied by AIA Document G706A, Affidavit of Release of Liens (latest edition) or such other form as may be prescribed by the Owner; .3 A certificate evidencing that the Contractor’s liability insurance and Performance Bond remain in effect during the one-year correction period following Substantial Completion as set forth in Section 12.2.2.1 and 12.2.2.2; .4 A written statement that the Contractor knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract Documents; .5 Consent of surety to final payment, submitted on AIA Document G707 (latest edition) or other form prescribed by the Owner; Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 9 .6 Other data required by the Owner establishing payment or satisfaction of obligations, such as receipts, releases and waivers of claims, security interests or encumbrances arising out of the Contract, to the extent and in such form as may be prescribed by the Owner; .7 A certified building location survey and as-built site plan in the form and number required by the Contract Documents; .8 All warranties and bonds required by the Contract Documents; and .9 Record Documents and return of Contract Documents as provided therein. § 9.10.4 Final acceptance of construction by the Owner is final approval of the Project only in the sense that it has been constructed, cleaned up, and completed in apparent substantial compliance with the Contract Documents. Said final acceptance is stipulated to mean a written acceptance by the Owner’s City Council. The certificate of completion submitted by Owner’s representative and approved by the Owner’s City Council shall constitute final acceptance of the Work and materials included in the Contract on the date of such approval, subject to the provision any such approval, acceptance, or payment as herein provided shall not constitute an acceptance of any unauthorized or defective work, or of any improper work or material. § 9.11 ASSIGNMENT § 9.11.1 No assignment by the Contractor of any principal contract or any part thereof, or of the funds to be received thereunder by the Contractor, will be recognized unless such assignment has had the written approval of the Owner and the Surety has been given due notice of such assignment and has furnished written consent thereto. In addition to the usual recitals in the Assignment Contract, the following language must be set forth: "It is agreed that the funds to be paid to the Assignee under this Assignment are subject to prior lien/Iowa Code Chapter 573 claims for services rendered on materials supplied for the performance of all work called for in said Contract, in favor of all persons, firms or corporations rendering such services supplying such materials." PAGE 28 § 10.2.5 The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Contract Documents) to property referred to in Sections 10.2.1.2, 10.2.1.3 and 10.2.1.4 caused in whole or in part by the Contractor, a Subcontractor, a Sub-subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Sections 10.2.1.2, 10.2.1.3 and 10.2.1.4. The Contractor may make a Claim for the cost to remedy the damage or loss to the extent such damage or loss is attributable to acts or omissions of the Owner, Construction Manager or Architect or anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable, and not attributable to the fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition to the Contractor’s obligations under Section 3.18. … § 10.2.9 Contractor shall at all times, protect the excavation, trenches and/or the buildings from damage or rain water, spring water, ground water, backing up of drains, or sewers, etc., and provide all pumps, equipment, and enclosures to give this protection. Contractor shall provide all shoring, bracing, and sheeting as required for safety and for the proper execution of the Work, and shall remove when the Work is completed. At the end of the day’s work, all new work likely to be damaged shall be covered. During cold weather, the Contractor shall protect all work from damage at no additional expense to the Owner. If low temperatures make it impossible to continue operations safely in spite of cold weather precautions, work shall cease after notifying Owner and Architect. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 10 All other protective measures not mentioned above which may be required shall be furnished by the Contractor. § 10.2.10 The Owner has attempted to show on the plans all aboveground and underground facilities, including public and private utilities, which may be affected by the work. The location, depth, and size of each such facility shown on the plans is approximate only and is not guaranteed. Other underground facilities may exist, and their location may not be presently known or identified. It is the Contractor’s responsibility to determine the existence and exact location of all such facilities located within the construction area to avoid damage. Where existing facilities are shown in the Contract Documents or encountered within the construction area, it shall be the responsibility of the Contractor to notify the operators of those facilities prior to beginning any construction activities. The Contractor shall allow access to those facilities for necessary modification of services. The Contractor shall support, sustain, and protect existing pipes, conduits, poles, wires, and other apparatus located under, over, along, across, or adjacent to the work site. If such utilities are damaged through Contractor’s negligence, they will be repaired by the agencies having control of same, but the cost of such repairs shall be paid by the Contractor. The Contractor shall, prior to commencing any excavation or other operation that may affect underground facilities, notify the "Iowa One Call" underground facility locate system, established pursuant to Iowa Code Chapter 480. The Contractor shall, if requested by the operator of an underground facility, assist in the location of its facilities; provided, however, the Owner shall not be responsible to the Contractor or to any operator of an underground facility for the cost of locating such facility, or for any damage to such facility that occurs in attempting to locate it, or for any damage to the facility occasioned by the Contractor’s performance of work under the contract. Claims for additional compensation will not be allowed to the Contractor for any interference, delay, or additional work occasioned by the location or adjustment of aboveground or underground facilities, or connections thereto. PAGE 29 § 10.3.2 Upon receipt of the Contractor’s notice, the Owner shall obtain the services of a licensed laboratory to verify the presence or absence of the material or substance reported by the Contractor and, in the event such material or substance is found to be present, to cause it to be rendered harmless. Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the Contractor, Construction Manager and Architect the names and qualifications of persons or entities who are to perform tests verifying the presence or absence of the material or substance or who are to perform the task of removal or safe containment of the material or substance. The Contractor, the Construction Manager and the Architect will promptly reply to the Owner in writing stating whether or not any of them has reasonable objection to the persons or entities proposed by the Owner. If the Contractor, Construction Manager or Architect has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Contractor, the Construction Manager and the Architect have no reasonable objection. When the material or substance has been rendered harmless, Work in the affected area shall resume upon written agreement of the Owner and Contractor. By Change Order, the Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor’s reasonable additional costs of shutdown, delay, and start-up.resume. § 10.3.3 To the fullest extent permitted by law, the Owner shall indemnify and hold harmless the Contractor, Subcontractors, Construction Manager, Architect, their consultants, and agents and employees of any of them from and against claims, damages, losses, and expenses, including but not limited to attorneys’ fees, arising out of or resulting from performance of the Work in the affected area if in fact the material or substance presents the risk of bodily injury or death as described in Section 10.3.1 and has not been rendered harmless, provided that such claim, damage, loss, or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself), except to the extent that such damage, loss, or expense is due to the fault or negligence of the party seeking indemnity. PAGE 30 § 11.2.1 The Owner shall purchase and maintain insurance of the types and limits of liability, containing the endorsements, and subject to the terms and conditions, as described in the Agreement or elsewhere in the Contract Documents. The Owner shall purchase and maintain the required insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 11 § 11.2.1 The Owner will purchase and maintain Builder’s Risk Insurance on this project. The Owner shall purchase and maintain the required insurance from an insurance company or insurance companies lawfully authorized to issue insurance in the jurisdiction where the Project is located. § 11.2.2 Failure to Purchase Required Property Insurance. If the Owner fails to purchase and maintain the required property insurance, with all of the coverages and in the amounts described in the Agreement or elsewhere in the Contract Documents, the Owner shall inform both the Contractor and the Construction Manager, separately and in writing, prior to commencement of the Work. Upon receipt of notice from the Owner, the Contractor may delay commencement of the Work and may obtain insurance that will protect the interests of the Contractor, Subcontractors, and Sub-Subcontractors in the Work. When the failure to provide coverage has been cured or resolved, the Contract Sum and Contract Time shall be equitably adjusted. In the event the Owner fails to procure coverage, the Owner waives all rights against the Contractor, Subcontractors, and Sub-subcontractors to the extent the loss to the Owner would have been covered by the insurance to have been procured by the Owner. The cost of the insurance shall be charged to the Owner by a Change Order. If the Owner does not provide written notice, and the Contractor is damaged by the failure or neglect of the Owner to purchase or maintain the required insurance, the Owner shall reimburse the Contractor for all reasonable costs and damages attributable thereto. § 11.2.3 Notice of Cancellation or Expiration of Owner’s Required Property Insurance. Within three (3) business days of the date the Owner becomes aware of an impending or actual cancellation or expiration of any property insurance required by the Contract Documents, the Owner shall provide notice directly to the Contractor, and separately to the Construction Manager, of such impending or actual cancellation or expiration. Unless the lapse in coverage arises from an act or omission of the Contractor: (1) the Contractor, upon receipt of notice from the Owner, shall have the right to stop the Work until the lapse in coverage has been cured by the procurement of replacement coverage by either the Owner or the Contractor; (2) the Contract Time and Contract Sum shall be equitably adjusted; and (3) the Owner waives all rights against the Contractor, Subcontractors, and Sub-subcontractors to the extent any loss to the Owner would have been covered by the insurance had it not expired or been cancelled. If the Contractor purchases replacement coverage, the cost of the insurance shall be charged to the Owner by an appropriate Change Order. Contractor. The furnishing of notice by the Owner shall not relieve the Owner of any contractual obligation to provide required insurance. … § 11.3.1 The Owner and Contractor waive Contractor waives all rights against (1) each other the Owner and any of their its subcontractors, sub-subcontractors, agents, and employees, each of the other; employees; (2) the Construction Manager and Construction Manager’s consultants; (3) the Architect and Architect’s consultants; (4) other Contractors and any of their subcontractors, sub-subcontractors, agents, and employees; and (5) Separate Contractors, if any, and any of their subcontractors, sub-subcontractors, agents, and employees, for damages caused by fire, or other causes of loss, to the extent those losses are covered by property insurance required by the Agreement or other property insurance applicable to the Project, except including such rights as they have to proceeds of such insurance. The Owner or Contractor, as appropriate, shall require similar written waivers in favor of the individuals and entities identified above from the Construction Manager, Construction Manager’s consultants, Architect, Architect’s consultants, other Contractors, Separate Contractors, subcontractors, and sub-subcontractors. The policies of insurance purchased and maintained by each person or entity agreeing to waive claims pursuant to this Section 11.3.1 shall not prohibit this waiver of subrogation. This waiver of subrogation shall be effective as to a person or entity (1) even though that person or entity would otherwise have a duty of indemnification, contractual or otherwise, (2) even though that person or entity did not pay the insurance premium directly or indirectly, or (3) whether or not the person or entity had an insurable interest in the damaged property. § 11.3.2 If during the Project construction period the Owner insures properties, real or personal or both, at or adjacent to the site by property insurance under policies separate from those insuring the Project, or if after final payment property insurance is to be provided on the completed Project through a policy or policies other than those insuring the Project during the construction period, to the extent permissible by such policies, the Owner waives all rights in accordance with the terms of Section 11.3.1 for damages caused by fire or other causes of loss covered by this separate property insurance. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 12 The Owner, at the Owner’s option, may purchase and maintain insurance that will protect the Owner against loss of use of the Owner’s property, or the inability to conduct normal operations, due to fire or other causes of loss. The Owner waives all rights of action against the Contractor, Architect, and Construction Manager for loss of use of the Owner’s property, due to fire or other hazards however caused. PAGE 31 § 11.5.1 A loss insured under the property insurance required by the Agreement shall be adjusted by the Owner as fiduciary and made payable to the Owner as fiduciary for the insureds, as their interests may appear, subject to requirements of any applicable mortgagee clause and of Section 11.5.2. The Owner shall pay the Construction Manager, Architect and Contractor their just shares of insurance proceeds received by the Owner, and by appropriate agreements the Construction Manager, Architect and Contractor shall make payments to their consultants and Subcontractors in similar manner. § 11.5.2 Prior to settlement of an insured loss, the Owner shall notify the Contractor of the terms of the proposed settlement as well as the proposed allocation of the insurance proceeds. The Contractor shall have 14 days from receipt of notice to object to the proposed settlement or allocation of the proceeds. If the Contractor does not object, the Owner shall settle the loss and the Contractor shall be bound by the settlement and allocation. Upon receipt, the Owner shall deposit the insurance proceeds in a separate account and make the appropriate distributions. Thereafter, if no other agreement is made or the Owner does not terminate the Contract for convenience, the Owner and Contractor shall execute a Change Order for reconstruction of the damaged or destroyed Work in the amount allocated for that purpose. If the Contractor timely objects to either the terms of the proposed settlement or the allocation of the proceeds, the Owner may proceed to settle the insured loss, and any dispute between the Owner and Contractor arising out of the settlement or allocation of the proceeds shall be resolved pursuant to Article 15. Pending resolution of any dispute, the Owner may issue a Construction Change Directive for the reconstruction of the damaged or destroyed Work. § … § 12.2.2.1 In addition to the Contractor’s obligations under Section 3.5, if, within one year after the date of Substantial Final Completion of the Work or designated portion thereof, or after the date for commencement of warranties established under Section 9.9.1, or by terms of any applicable special warranty required by the Contract Documents, Documents,the period of the required maintenance bond, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. During the one-year period for correction of Work, if the Owner fails to notify the Contractor and give the Contractor an opportunity to make the correction, the Owner waives the rights to require correction by the Contractor and to make a claim for breach of warranty. If the Contractor fails to correct nonconforming Work within a reasonable time during that period after receipt of notice from the Owner, Construction Manager or Architect, the Owner may correct it in accordance with Section 2.5. Where the Contractor corrects defective work during the initial one (1) year period after Final Completion, if the Owner discovers defects in the corrected work within one (1) year after the repairs are made, then the Contractor shall be obligated, upon written notice from the Owner, to correct such defects within one (1) year from the date that repairs were made. … § 12.2.2.3 The one-year period for correction of Work shall not be extended by corrective Work performed by the Contractor pursuant to this Section 12.2. PAGE 32 Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 13 § 12.2.6 If the Contractor fails or refuses to correct the Work in accordance with its obligations under the Contract Documents after written notice from the Owner, then the Owner may correct the Work and the Contractor shall be liable for the costs to correct the Work, any related architectural, engineering or other consulting costs, attorney’s fees and expenses, and fines or penalties, if any. Any amounts due to the Owner from the Contractor under this Section may be withheld from the balance of the Contract Sum not yet paid. … The Contract shall be governed by the law of the place where the Project is located excluding that jurisdiction’s choice of law rules. If the parties have selected arbitration as the method of binding dispute resolution, the Federal Arbitration Act shall govern Section 15.4.laws of the State of Iowa. § 13.1.1 The Contractor agrees that it will comply with all applicable Federal, State, and local laws, statutes, codes, rules, and regulations having jurisdiction over the Project, including Owner policies. Contractor shall take all necessary precautions to keep the site and work in compliance with the safety and health regulations for construction issued by the Bureau of Labor Standards of the U.S. Department of Labor as well as the Occupational Safety and Health Standards, as amended and as enforced by the State of Iowa … § 13.3.2.1 The Owner shall not be precluded or estopped by any measurement, estimate, or certificate made either before or after the completion and acceptance of the work and payment therefore, from showing the true amount and character of the work performed and the materials furnished by the Contractor, or from showing that any such measurement, estimate, or certificate is untrue or incorrectly made, or from showing that the work or materials do not in fact conform to the contract documents. § 13.3.2.2 The Owner shall not be precluded or estopped, notwithstanding any such measurement, estimate, or certificate and payment in accordance therewith, from recovering from the Contractor and its Surety such damages as it may sustain, and all outlay and expense it incurs, by reason of the Contractor’s failure to comply with the terms of the Contract. Neither the acceptance by the Owner nor any of its representatives, nor any payment for acceptance of the whole or any part of the work, nor any extension of time, nor any possession taken by the Owner, shall operate as a waiver of any portion of the contract, or any powers herein reserved, or any right to damages herein provided. A waiver of any breach of the contract shall not be held to be a waiver of any other subsequent breach. §13.3.2.3 The Contractor hereby waives any claims it may hereafter be entitled to assert against the Owner, its officers, agents, employees, or consultants, on its behalf or on behalf of its employees, agents, subcontractors, sub-subcontractors, and suppliers, for loss of or damage to personal property, tools, or equipment owned by it or its employees, agents, subcontractors, sub-subcontractors, and suppliers, which loss or damage is sustained on the Owner’s project property, or which occurs during work on the project, and the Contractor agrees to assume liability or responsibility for such claims and to procure insurance to cover its exposure in that regard PAGE 33 § 13.4.1 Tests, inspections, and approvals of portions of the Work shall be made as required by the Contract Documents and by applicable laws, statutes, ordinances, codes, rules, and regulations or lawful orders of public authorities. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections, and approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall bear all related costs of tests, inspections, and approvals. The Contractor shall give the Construction Manager and Architect timely notice of when and where tests and inspections are to be made so that the Construction Manager and Architect may be present for such procedures. The Owner shall bear costs of tests, inspections, or approvals that do not become requirements until after bids are received or negotiations concluded. The Owner shall directly arrange and pay for tests, inspections, or approvals where building codes or applicable laws or regulations so require. … § 13.6 Rebates Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 14 § 13.6.1 Owner shall have the right to apply for, and secure all rebates which are available when Bids are received. Contractor shall provide invoices, itemizations, and cooperation to the Owner in this regard. § 13.7 Liquidated Damages § 13.7.1 Time is of the essence of the contract. As delay in the diligent prosecution of the work may inconvenience the public, obstruct traffic, interfere with business, and/or increase costs to the Owner such as engineering, administration, and inspection, it is important the work be prosecuted vigorously to completion. Should the Contractor, or in case of default the surety, fail to complete the work within the contract time plus such extensions of time as may be allowed by the Owner, a deduction at the liquidated damages rate specified in the contract will be made for each and every calendar day or working day, whichever is specified, that such contract remains uncompleted after expiration of the contract time. In either event, the Contractor or the Contractor’s surety shall be responsible for all costs incident to the completion of the work, and shall be required to pay to the Owner liquidated damages stipulated in the Contract. § 13.7.2 The liquidated damages rate specified in the Contract Documents is hereby agreed upon as the true and actual damages due the Owner for loss to the Owner and to the public due to obstruction of traffic, interference with business, and/or increased costs to the Owner such as engineering, administration, and inspection after the expiration of the contract time, or extension thereof. Such liquidated damages may be deducted from any money due or to become due the Contractor under the contract, and the Contractor and its surety shall be liable for any liquidated damages in excess of the amount due the Contractor. § 13.7.3 . Allowing the Contractor to continue and finish the work, or any part of it, after the expiration of the contract time or extension thereof shall in no way operate as a waiver on the part of the Owner of any of its rights or remedies under the contract, including its right to liquidated damages pursuant to this provision. PAGE 34 § 14.1.1 The Contractor may terminate the Contract if the Work is stopped for a period of 30 consecutive days through no act or fault of the Contractor, a Subcontractor, a Sub-subcontractor, their agents or employees, or any other persons or entities performing portions of the Work, for any of the following reasons: .1 Issuance of an order of a court or other public authority having jurisdiction that requires all Work to be stopped; .2 An act of government, such as a declaration of national emergency, that requires all Work to be stopped; .3 Because the Construction Manager has not certified or the Architect has not issued a Certificate for Payment and has not notified the Contractor of the reason for withholding certification as provided in Section 9.4, or because the Owner has not made payment on a Certificate for Payment within the time stated in the Contract Documents; or .4 The Owner has failed to furnish to the Contractor reasonable evidence as required by Section 2.2. § 14.1.2 The Contractor may terminate the Contract if, through no act or fault of the Contractor, a Subcontractor, a Sub-subcontractor, their agents or employees, or any other persons or entities performing portions of the Work, repeated suspensions, delays, or interruptions of the entire Work by the Owner as described in Section 14.3, constitute in the aggregate more than 100 percent of the total number of days scheduled for completion, or 120 days in any 365-day period, whichever is less. § 14.1.3 If one of the reasons described in Section 14.1.1 or 14.1.2 exists, the Contractor may, upon seven days’ notice to the Owner, Construction Manager and Architect, terminate the Contract and recover from the Owner payment for Work executed, as well as reasonable overhead and profit on Work not executed, and costs incurred by reason of such termination. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 15 § 14.1.4 If the Work is stopped for a period of 60 consecutive days through no act or fault of the Contractor, a Subcontractor, a Sub-subcontractor, or their agents or employees, or any other persons performing portions of the Work because the Owner has repeatedly failed to fulfill the Owner’s obligations under the Contract Documents with respect to matters important to the progress of the Work, the Contractor may, upon seven additional days’ notice to the Owner, Construction Manager and Architect, terminate the Contract and recover from the Owner as provided in Section 14.1.3. § 14.1.1 The Contractor has no right to stop Work as a consequence of non-payment. In the event of any disagreement between the Contractor and Owner involving the Contractor’s entitlement to payment, the Contractor’s only remedy is to file a Claim in accordance with Article 15. The Contractor must diligently proceed with the Work pending resolution of the Claim. If, however, an Application for Payment has been approved for payment by the Owner, and the Owner fails to make payment within sixty (60) days of the approval for payment by the Owner, the Contractor may upon ten (10) days written notice to the Owner, stop work if payment is not made by the Owner within ten (10) days following the notice. … .1 repeatedly refuses or fails to supply enough properly skilled workers Fails to supply adequate properly skilled workers, proper equipment or proper materials; .2 fails Fails to make payment to Subcontractors or suppliers for material or labor in accordance with the respective agreements between the Contractor and the Subcontractors or suppliers; .3 repeatedly disregards applicable laws, statutes, ordinances, codes, rules and regulations, or lawful orders of a public authority; orFails to comply with any laws, ordinances, or rules, regulations or orders of a public authority having jurisdiction over the Project; .4 otherwise is guilty of substantial breach of a provision of the Contract Documents.Fails to perform the Work in accordance with the Contract Documents or otherwise breaches any provision of the Contract Documents; .5 Anticipatorily breaches or repudiates the Contract; .6 Fails to make satisfactory progress in the prosecution of the Work required by the Contract; or .7 Endangers the performance of this Contract; .8 Fails to carry on the Work in an acceptable manner; .9 Fails or refuses to remove and correct rejected, defective, unacceptable or nonconforming work or materials; .10 Disregard of laws, ordinances, or instructions of the Architect or Owner. § 14.2.2 When any of the reasons described in Section 14.2.1 exist, after consultation with the Construction Manager, and upon certification by the Architect that sufficient cause exists to justify such action, the Owner may, without prejudice to any other rights or remedies of the Owner and after giving the Contractor and the Contractor’s surety, if any, seven days’ notice, terminate employment of the Contractor and may, subject to any prior rights of the surety: .1 Exclude the Contractor from the site and take possession of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor; .2 Accept assignment of subcontracts pursuant to Section 5.4; and .3 Finish the Work by whatever reasonable method the Owner may deem expedient. Upon written request of the Contractor, the Owner shall furnish to the Contractor a detailed accounting of the costs incurred by the Owner in finishing the Work.Contractorseven days’ notice of default, terminate employment of the Contractor. If the default is not cured, the termination for default is effective on the date specified in the Owner’s written notice. However, if the Owner determines that default contributes to the curtailment of an essential service or poses an immediate threat to life, health, or property, the Owner may terminate the Contract immediately upon issuing oral or written notice to the Contractor without any prior notice or opportunity to cure. In addition to any other remedies provided by law or the Contract, the Contractor must compensate the Owner for additional costs that foreseeably would be incurred by the Owner, whether the costs are actually incurred or not, to obtain substitute performance. A termination for default is a termination for convenience if the termination for default is later found to be without justification. Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 16 § 14.2.3 When the Owner terminates the Contract for one of the reasons stated in Section 14.2.1, the Contractor shall not be entitled to receive further payment until the Work is finished. § 14.2.4 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including compensation for the Construction Manager’s and Architect’s services and expenses made necessary thereby, and other damages incurred by the Owner and not expressly waived, such excess shall be paid to the Contractor. If such costs and damages exceed the unpaid balance, the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case may be, shall, upon application, be certified by the Initial Decision Maker after consultation with the Construction Manager, and this obligation for payment shall survive termination of the Contract. § 14.2.3 Upon receipt of written notice from the Owner of termination, the Contractor must: .1 Cease operations as directed by the Owner in the notice and, if required by the Owner, participate in an inspection of the Work with the Owner, and the Architect to record the extent of completion thereof, to identify the Work remaining to be completed or corrected, and to determine what temporary facilities, tools, equipment and construction machinery are to remain at the Site pending completion of the Work; .2 Complete or correct the items directed by the Owner, and take actions necessary, or that the Owner may direct, for the protection and preservation of any stored materials and equipment and completed Work; .3 Unless otherwise directed by the Owner, remove its tools, equipment and construction machinery from the Site, and .4 Except as directed by the Owner, terminate all existing subcontracts and purchase orders and enter into no further subcontracts or purchase orders. § 14.2.4 Following written notice from the Owner of termination, the Owner may: .1 Take possession of the Site and of all materials and equipment thereon, and at the Owner’s option, such temporary facilities, tools, construction equipment and machinery thereon owned or rented by the Contractor that the Owner elects to utilize in completing the Work; .2 Accept assignment of subcontracts pursuant to section 5.4 and purchase orders, and/or .3 Complete the Work by whatever reasonable method the Owner may deem expedient. § 14.2.5 Upon termination for cause, Contractor shall take those actions described in Section 14.2.3, and Owner may take those actions described in Section 14.2.4, subject to prior rights of Contractor’s Surety, as applicable. § 14.2.6 When the Owner terminates the Contract for one of the reasons stated in Section 14.2.1, the Contractor shall not be entitled to receive further payment until the Work is finished. § 14.2.7 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including actual or Liquidated Damages,compensation for the Construction Manager’s and Architect’s services and expenses made necessary thereby, and other damages incurred by the Owner and not expressly waived, such excess shall be paid to the Contractor. If such costs and damages exceed the unpaid balance, the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case may be, shall, upon application, be certified by the Initial Decision Maker after consultation with the Construction Manager, and this obligation for payment shall survive termination of the Contract. § 14.2.8 If the Contractor files for protection, or a petition is filed against it, under the Bankruptcy laws, the Contractor wishes to affirm the Contract, Contractor shall immediately file with the Bankruptcy Court a motion to affirm the Contract and shall provide satisfactory evidence to Owner and to the Court of its ability to cure all present defaults and its ability to timely and successfully complete the Work. If Contractor does not make such an immediate filing, Contractor accepts that Owner shall petition the Bankruptcy Court to lift the Automatic Stay and permit Owner to terminate the Contract. PAGE 36 § 14.4.3 In case of such termination for the Owner’s convenience, the Owner shall pay the Contractor for Work properly executed; costs incurred by reason of the termination, including costs attributable to termination of Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 17 Subcontracts; and the termination fee, if any, set forth in the Agreement.Contractor will be entitled to compensation only for the following items: .1 Payment for acceptable Work performed up to the date of termination; .2 The costs of preservation and protection of the Work if requested to do so by the Owner; .3 The cost of terminating the following contracts. including: a. Purchased materials but only if not returnable and provided to the Owner, or the restocking or return charge, if any, if returnable at the Owner’s written election; b. Equipment rental contracts if not terminable at no cost but not to exceed an amount equal to thirty (30) days rental; c. Documented transportation costs associated with removing Contractor-owned equipment; d. Documented demobilization and close-out costs; and e. Overhead and profit on the foregoing not to exceed ten percent (10%). The Contractor will not be compensated for the cost of any idled employees unless the employee is under a written employment contract entitling the employee to continued employment after termination of the Contract and the employee cannot be assigned to other work provided that in all events the Contractor’s costs must be limited to thirty (30) days of employment costs from the date of the notice of termination. The Contractor is not entitled to any other costs or compensation (including lost or expected profit, uncompensated overhead or related expenses, or the cost of preparing and documenting its compensable expenses under this Section 14.4.4 as a consequence of the Owner’s termination of the Contract for convenience. The Contractor conclusively and irrevocably waives its right to any other compensation or damages (compensatory or punitive) arising from termination of the Contract. If the Owner and the Contractor are unable to agree upon the amounts specified in this subsection, the Contractor may submit a Claim as provided in Article 15. The Claim must be limited to resolution of the amounts specified in Subsections 14.4.4.1, 14.4.4.2, and 14.4.4.3 of this Subsection 14.4.4. No other cost, damages or expenses may be claimed or paid to the Contractor or considered as part of the Claim, the same being hereby conclusively and irrevocably waived by the Contractor. Any such Claim must be delivered to the Owner within thirty (30) days of the termination of the Contract and must contain a written statement setting forth the specific reasons and supporting calculations and documentation as to the amounts the Contractor claims to be entitled to under this Subsection as a result of the termination of the Contract. § 14.4.4 The Contractor’s obligations surviving final payment under the Contract, including without limitation those with respect to insurance, indemnification, and correction of Work that has been completed at the time of termination, remains effective notwithstanding termination for convenience of the Owner. PAGE 37 The Owner and Contractor shall commence all Claims and causes of action against the other and arising out of or related to the Contract, whether in contract, tort, breach of warranty or otherwise, in accordance with the requirements of the binding dispute resolution method selected in the Agreement and within the period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. Final Acceptance of the Work by Owner. The Owner and Contractor waive all Claims and causes of action not commenced in accordance with this Section 15.1.2. … § 15.1.3.1 Claims by either the Owner or Contractor, where the condition giving rise to the Claim is first discovered prior to expiration of the period for correction of the Work set forth in Section 12.2.2, shall be initiated by notice to the other party and to the Initial Decision Maker with a copy sent to the Construction Manager and Architect, if the Architect is not serving as the Initial Decision Maker. Claims by either party under this Section 15.1.3.1 shall be initiated within 21 days after a reasonable time after the occurrence of the event giving rise to such Claim or within 21 days a reasonable time after the claimant first recognizes the condition giving rise to the Claim, whichever is later. PAGE 38 § 15.1.7 Waiver of Claims for Consequential Damages. The Contractor and Owner waive Claims against each other waives Claims against the Owner for consequential damages arising out of or relating to this Contract. This mutual waiver includes Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 18 .1 damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee productivity or of the services of such persons; and .2 damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed there, for losses of financing, business and reputation, and for loss of profit except anticipated profit arising directly from the Work.profit.. This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14. Nothing contained in this Section 15.1.7 shall be deemed to preclude assessment of liquidated damages, when applicable, in accordance with the requirements of the Contract Documents. … § 15.2.1 Claims, excluding those where the condition giving rise to the Claim is first discovered after expiration of the period for correction of the Work set forth in Section 12.2.2 or arising under Sections 10.3, 10.4, and 11.5, shall be referred to the Initial Decision Maker for initial decision. The Architect will serve as the Initial Decision Maker, unless otherwise indicated in the Agreement. Except for those Claims excluded by this Section 15.2.1, an initial decision shall be required as a condition precedent to mediation of any Claim. If an initial decision has not been rendered within 30 days after the Claim has been referred to the Initial Decision Maker, the party asserting the Claim may demand request mediation and binding dispute resolution without a decision having been rendered. rendered to the extent provided in this agreement. Unless the Initial Decision Maker and all affected parties agree, the Initial Decision Maker will not decide disputes between the Contractor and persons or entities other than the Owner. … § 15.2.6 Either party may file for The parties may participate in mediation of an initial decision at any time, subject to the terms of Section 15.2.6.1.upon mutual agreement of the parties. § 15.2.6.1 Either party may, within 30 days from the date of receipt of an initial decision, demand in writing that the other party file for mediation. If such a demand is made and the party receiving the demand fails to file for mediation within 30 days of receipt thereof, then both parties waive their rights to mediate or pursue binding dispute resolution proceedings with respect to the initial decision. § 15.2.8 If a Claim relates to or is the subject of a mechanic’s lien, the party asserting such Claim may proceed in accordance with applicable law to comply with the lien notice or filing deadlines. § 15.3.1 Claims, disputes, or other matters in controversy arising out of or related to the Contract, except those waived as provided for in Sections 9.10.4, 9.10.5, and 15.1.7, shall be subject to mediation as a condition precedent to binding dispute resolution.Not Applicable § 15.3.2 The parties shall endeavor to resolve their Claims by mediation which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of the Agreement. A request for mediation shall be made in writing, delivered to the other party to the Contract, and filed with the person or entity administering the mediation. The request may be made concurrently with the filing of binding dispute resolution proceedings but, in such event, mediation shall proceed in advance of binding dispute resolution proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. If an arbitration is stayed pursuant to this Section 15.3.2, the parties may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings. § 15.3.3 Either party may, within 30 days from the date that mediation has been concluded without resolution of the dispute or 60 days after mediation has been demanded without resolution of the dispute, demand in writing that the other party file for binding dispute resolution. If such a demand is made and the party receiving the demand fails to file Additions and Deletions Report for AIA Document A232 –2019.Copyright © 1992, 2009, and 2019. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 19 for binding dispute resolution within 60 days after receipt thereof, then both parties waive their rights to binding dispute resolution proceedings with respect to the initial decision. § 15.3.2 The parties shall endeavor in good faith to resolve claims, disputes and other matters in question between them by mutual agreement and may, by mutual agreement and in their discretion, submit same to non-binding mediation which shall be in accordance with Iowa Code Chapter 679C, unless otherwise mutually agreed by the parties. Requests for mediation shall be given in writing to the other party to this Agreement. If the Owner and Contractor are unable to mutually agree upon a mediator in writing within sixty (60) days of receiving the written request for mediation, either party may then institute legal or equitable proceedings. Mediation shall be voluntary only and shall not be a prerequisite to litigation or other means of dispute resolution. § 15.4 Arbitration § 15.4.1 If the parties have selected arbitration as the method for binding dispute resolution in the Agreement, any Claim subject to, but not resolved by, mediation shall be subject to arbitration which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of the Agreement. The Arbitration shall be conducted in the place where the Project is located, unless another location is mutually agreed upon. A demand for arbitration shall be made in writing, delivered to the other party to the Contract, and filed with the person or entity administering the arbitration.The party filing a notice of demand for arbitration must assert in the demand all Claims then known to that party on which arbitration is permitted to be demanded. § 15.4.1.1 A demand for arbitration shall be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on the Claim would be barred by the applicable statute of limitations. For statute of limitations purposes, receipt of a written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of legal or equitable proceedings based on the Claim. § 15.4.2 The award rendered by the arbitrator or arbitrators shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof. § 15.4.3 The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to the Agreement, shall be specifically enforceable under applicable law in any court having jurisdiction thereof. § 15.4.4 Consolidation or Joinder § 15.4.4.1 Subject to the rules of the American Arbitration Association or other applicable arbitration rules, either party may consolidate an arbitration conducted under this Agreement with any other arbitration to which it is a party provided that (1) the arbitration agreement governing the other arbitration permits consolidation, (2) the arbitrations to be consolidated substantially involve common questions of law or fact, and (3) the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s). § 15.4.4.2 Subject to the rules of the American Arbitration Association or other applicable arbitration rules, either party may include by joinder persons or entities substantially involved in a common question of law or fact whose presence is required if complete relief is to be accorded in arbitration, provided that the party sought to be joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent. § 15.4.4.3 The Owner and Contractor grant to any person or entity made a party to an arbitration conducted under this Section 15.4, whether by joinder or consolidation, the same rights of joinder and consolidation as those of the Owner and Contractor under this Agreement. AIA Document D401 – 2003. Copyright © 1992 and 2003. All rights reserved. “The American Institute of Architects,” “American Institute of Architects,” “AIA,” the AIA Logo, and “AIA Contract Documents” are trademarks of The American Institute of Architects. This document was produced at 10:58:13 ET on 01/15/2026 under Order No.4104251064 which expires on 12/31/2026, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, e-mail docinfo@aiacontracts.com. User Notes:(1634873933) 1 Certification of Document’s Authenticity AIA® Document D401™ – 2003 I, Kerry Nelsen, hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with its associated Additions and Deletions Report and this certification at 10:58:13 ET on 01/15/2026 under Order No. 4104251064 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA® Document A232™ – 2019, General Conditions of the Contract for Construction, Construction Manager as Adviser Edition, other than those additions and deletions shown in the associated Additions and Deletions Report. _____________________________________________________________ (Signed) _____________________________________________________________ (Title) _____________________________________________________________ (Dated) CITY OF WAUKEE OPN PROJECT NO. 25821000 EXISTING PD/FD BLDG RENOVATION EARLY BID PACKAGE INSURANCE EXHIBIT 00 60 00.02.1 - 1 SECTION 00 60 00.02.1 EXHIBIT A INSURANCE AND BONDS Insurance Minimum Coverage Amounts Workers’ Compensation Statutory Limits Employer’s Liability, including “Stop Gap” coverage and USL&H if applicable $500,000 each accident $500,000 disease-policy limit $500,000 disease-each employee Commercial General Liability (Occurrence Basis): Applicable for Contract Sum in Excess of $500,000 $5,000,000 each occurrence $5,000,000 products/completed operations aggregate $5,000,000 general aggregate (per project) Steel Erectors $5,000,000 each occurrence $5,000,000 products/completed operations aggregate $5,000,000 general aggregate (per project) All Other Contracts $2,000,000 each occurrence $2,000,000 products/completed operations aggregate $2,000,000 general aggregate (per project) Commercial Automobile Liability $1,000,000 any one accident or loss Professional Liability Required for all design related work $1,000,000 each claim $1,000,000 annual aggregate Contractors Pollution Liability Required for all earth work Aircraft Liability (Drone or Unmanned Aerial System) Required for aerial drone usage $1,000,000 each claim $1,000,000 annual aggregate $2,000,000 per occurrence Bonding Requirements Payment and Performance Bonds for all Contracts in the amount of the applicable Contract Sum. The bidder’s security shall be in an amount equal to five percent (5%) of the total amount of the bid Determined by adding the base bid and all alternates). Contractor’s surety must be on the current list of ‘Surety Companies Acceptable on Federal Bonds’ published in Treasury Department Circular Number 570 and licensed to do business in the state where the Project is located. CITY OF WAUKEE OPN PROJECT NO. 25821000 EXISTING PD/FD BLDG RENOVATION EARLY BID PACKAGE INSURANCE EXHIBIT 00 60 00.02.1 - 2 ID Task Name Duration Start Finish 0 Waukee Existing PD/FD Building Renovation 363 days Thu 8/7/25 Fri 1/8/27 1 Design Development, Preconstruction, and Early Procurement 183 days Thu 8/7/25 Fri 4/24/26 2 Design Development 143 days Thu 8/7/25 Fri 2/27/26 3 Site Survey 45 days Thu 8/7/25 Thu 10/9/25 4 Site Plan Submittal Package 69 days Fri 10/10/25 Mon 1/19/26 5 Site Plan Submittal 1 day Tue 1/20/26 Tue 1/20/26 6 Site Plan Review (City)15 days Wed 1/21/26 Tue 2/10/26 7 Site Plan Approval 1 day Wed 2/11/26 Wed 2/11/26 8 Schematic Design 50 days Thu 8/7/25 Thu 10/16/25 9 Schematic Design Deliverable 1 day Fri 10/17/25 Fri 10/17/25 10 Design Development 38 days Mon 10/20/25 Thu 12/11/25 11 Design Development Deliverable 1 day Fri 12/12/25 Fri 12/12/25 12 Early Bid Packages - 100% Construction Documents 19 days Mon 10/20/25 Thu 11/13/25 13 Early Bid Packages Deliverable 1 day Fri 11/14/25 Fri 11/14/25 14 100% Construction Documents - Full Set (Remaining Pkgs)52 days Mon 12/15/25 Thu 2/26/26 15 100% Construction Documents - Full Set Deliverable 1 day Fri 2/27/26 Fri 2/27/26 16 PreConstruction 132 days Mon 10/20/25 Fri 4/24/26 17 Schematic Design Estimate 15 days Mon 10/20/25 Fri 11/7/25 18 Design Development Estimate 20 days Mon 12/15/25 Tue 1/13/26 19 Early Bid Packages - Prep for Bid 5 days Mon 11/17/25 Fri 11/21/25 20 Early Bid Packages Bidding 15 days Mon 11/24/25 Mon 12/15/25 21 Early Bid Packages - Bids Due 1 day Tue 12/16/25 Tue 12/16/25 22 Early Bid Packages - Award, Contracts, Insurance, etc.20 days Wed 12/17/25 Thu 1/15/26 23 Early Bid Packages - Contracts Executed (Council)5 days Fri 1/16/26 Thu 1/22/26 24 Full Buyout Prep for Bid (Remaining Pkgs)5 days Mon 3/2/26 Fri 3/6/26 25 Full Buyout Bidding (Remaining Pkgs)16 days Mon 3/9/26 Mon 3/30/26 26 Full Buyout (Remaining Pkgs) - Bids Due 1 day Tue 3/31/26 Tue 3/31/26 27 Full Buyout - City Council Public Hearing / Award Contract 1 day Mon 4/6/26 Mon 4/6/26 28 Full Buyout - Award, Contracts, Insurance, etc.9 days Tue 4/7/26 Fri 4/17/26 29 Full Buyout - City Council Contract & Bonds Approved 1 day Mon 4/20/26 Mon 4/20/26 30 Full Buyout - Contracts Executed & Ready to Mobilze 4 days Tue 4/21/26 Fri 4/24/26 31 Procurement 181 days Thu 1/22/26 Tue 10/6/26 32 Begin Early Procurement Process 0 days Thu 1/22/26 Thu 1/22/26 33 Begin Standard Procurement Process 0 days Fri 4/24/26 Fri 4/24/26 34 Site 95 days Mon 4/27/26 Tue 9/8/26 35 Site Grading 30 days Mon 4/27/26 Mon 6/8/26 36 Buyout ( site grading ) 1 day Mon 4/27/26 Mon 4/27/26 37 Submittal Development (site grading )5 days Tue 4/28/26 Mon 5/4/26 38 Ryan Submittal Review ( site grading )5 days Tue 5/5/26 Mon 5/11/26 39 Designer Submittal Approval ( site grading )14 days Tue 5/12/26 Mon 6/1/26 40 Fabrication & Delivery ( site grading )5 days Tue 6/2/26 Mon 6/8/26 41 Site Grading / Utilities 30 days Mon 4/27/26 Mon 6/8/26 42 Buyout ( site grading / utilities ) 1 day Mon 4/27/26 Mon 4/27/26 43 Submittal Development (site grading/utilities )5 days Tue 4/28/26 Mon 5/4/26 44 Ryan Submittal Review ( site grading / utilities )5 days Tue 5/5/26 Mon 5/11/26 45 Designer Submittal Approval ( site grading / utilities )14 days Tue 5/12/26 Mon 6/1/26 46 Fabrication & Delivery (utilities )5 days Tue 6/2/26 Mon 6/8/26 47 Landscaping 40 days Mon 4/27/26 Mon 6/22/26 48 Buyout ( landscaping ) 1 day Mon 4/27/26 Mon 4/27/26 49 Submittal Development ( landscaping )10 days Tue 4/28/26 Mon 5/11/26 50 Ryan Submittal Review ( landscaping )5 days Tue 5/12/26 Mon 5/18/26 ID Task Name Duration Start Finish 51 Designer Submittal Approval ( landscaping )14 days Tue 5/19/26 Mon 6/8/26 52 Fabrication & Delivery ( landscaping )10 days Tue 6/9/26 Mon 6/22/26 53 Site Lighting 60 days Mon 4/27/26 Mon 7/20/26 54 Buyout ( site lighting ) 1 day Mon 4/27/26 Mon 4/27/26 55 Submittal Development ( site lighting )15 days Tue 4/28/26 Mon 5/18/26 56 Ryan Submittal Review ( site lighting )5 days Tue 5/19/26 Tue 5/26/26 57 Designer Submittal Approval ( site lighting )14 days Wed 5/27/26 Mon 6/15/26 58 Fabrication & Delivery ( site lighting )5 wks Tue 6/16/26 Mon 7/20/26 59 Exterior Signage 95 days Mon 4/27/26 Tue 9/8/26 60 Buyout ( signage ) 1 day Mon 4/27/26 Mon 4/27/26 61 Submittal Development ( signage )15 days Tue 4/28/26 Mon 5/18/26 62 Ryan Submittal Review ( signage )5 days Tue 5/19/26 Tue 5/26/26 63 Designer Submittal Approval ( signage )14 days Wed 5/27/26 Mon 6/15/26 64 Fabrication & Delivery ( signage )60 days Tue 6/16/26 Tue 9/8/26 65 Foundation / Structure 65 days Mon 4/27/26 Mon 7/27/26 66 Concrete Foundations/Reinforcing 35 days Mon 4/27/26 Mon 6/15/26 67 Buyout ( concrete foundations ) 1 day Mon 4/27/26 Mon 4/27/26 68 Submittal Development ( concrete foundations )10 days Tue 4/28/26 Mon 5/11/26 69 Ryan Submittal Review ( concrete foundations )5 days Tue 5/12/26 Mon 5/18/26 70 Designer Submittal Approval ( concrete foundations )14 days Tue 5/19/26 Mon 6/8/26 71 Fabrication & Delivery ( concrete foundations )5 days Tue 6/9/26 Mon 6/15/26 72 Concrete Flatwork 35 days Mon 4/27/26 Mon 6/15/26 73 Buyout ( concrete flatwork ) 1 day Mon 4/27/26 Mon 4/27/26 74 Submittal Development ( concrete flatwork )10 days Tue 4/28/26 Mon 5/11/26 75 Ryan Submittal Review ( concrete flatwork )5 days Tue 5/12/26 Mon 5/18/26 76 Designer Submittal Approval ( concrete flatwork )14 days Tue 5/19/26 Mon 6/8/26 77 Fabrication & Delivery ( concrete flatwork )5 days Tue 6/9/26 Mon 6/15/26 78 Flatwork Concrete Reinforcing 45 days Mon 4/27/26 Mon 6/29/26 79 Buyout ( concrete Reinforcing ) 1 day Mon 4/27/26 Mon 4/27/26 80 Submittal Development ( concrete Reinforcing ) 10 days Tue 4/28/26 Mon 5/11/26 81 Ryan Submittal Review ( concrete Reinforcing ) 5 days Tue 5/12/26 Mon 5/18/26 82 Designer Submittal Approval ( concrete Reinforcing ) 14 days Tue 5/19/26 Mon 6/8/26 83 Fabrication & Delivery ( concrete Reinforcing ) 15 days Tue 6/9/26 Mon 6/29/26 84 Structural Steel 65 days Mon 4/27/26 Mon 7/27/26 85 Buyout ( structural steel ) 1 day Mon 4/27/26 Mon 4/27/26 86 Wide Flange (Building)34 days Tue 4/28/26 Mon 6/15/26 87 Submittal Development ( structural steel )5 days Tue 4/28/26 Mon 5/4/26 88 Ryan Submittal Review ( structural steel )5 days Tue 5/5/26 Mon 5/11/26 89 Designer Submittal Approval ( structural steel )14 days Tue 5/12/26 Mon 6/1/26 90 Fabrication & Delivery ( structural steel )10 days Tue 6/2/26 Mon 6/15/26 91 Structural Steel (Canopy)54 days Tue 4/28/26 Mon 7/13/26 92 Submittal Development ( structural steel )15 days Tue 4/28/26 Mon 5/18/26 93 Ryan Submittal Review ( structural steel )5 days Tue 5/19/26 Tue 5/26/26 94 Designer Submittal Approval ( structural steel )14 days Wed 5/27/26 Mon 6/15/26 95 Fabrication & Delivery 20 days Tue 6/16/26 Mon 7/13/26 96 Anchor Bolts/Embeds 54 days Tue 4/28/26 Mon 7/13/26 97 Submittal Development ( anchor bolts )15 days Tue 4/28/26 Mon 5/18/26 98 Ryan Submittal Review ( anchor bolts )5 days Tue 5/19/26 Tue 5/26/26 99 Designer Submittal Approval ( anchor bolts )14 days Wed 5/27/26 Mon 6/15/26 100 Fabrication & Delivery ( anchor bolts )20 days Tue 6/16/26 Mon 7/13/26 101 Misc. Steel Fabrications 54 days Tue 4/28/26 Mon 7/13/26 ID Task Name Duration Start Finish 102 Submittal Development ( misc. steel fabrications )15 days Tue 4/28/26 Mon 5/18/26 103 Ryan Submittal Review ( misc. steel fabrications )5 days Tue 5/19/26 Tue 5/26/26 104 Designer Submittal Approval ( misc. steel fabrications )14 days Wed 5/27/26 Mon 6/15/26 105 Fabrication & Delivery ( misc. steel fabrications )20 days Tue 6/16/26 Mon 7/13/26 106 Bar joists / Decking 65 days Mon 4/27/26 Mon 7/27/26 107 Buyout ( bar joists / decking ) 1 day Mon 4/27/26 Mon 4/27/26 108 Submittal Development ( bar joists / decking )15 days Tue 4/28/26 Mon 5/18/26 109 Ryan Submittal Review ( bar joists / decking )5 days Tue 5/19/26 Tue 5/26/26 110 Designer Submittal Approval ( bar joists / decking )14 days Wed 5/27/26 Mon 6/15/26 111 Fabrication & Delivery ( bar joists / decking )6 wks Tue 6/16/26 Mon 7/27/26 112 Envelope 91 days Fri 1/23/26 Mon 6/1/26 113 Glazing Exterior 91 days Fri 1/23/26 Mon 6/1/26 114 Buyout ( glazing exterior ) 1 day Fri 1/23/26 Fri 1/23/26 115 Submittal Development ( glazing exterior )15 days Mon 1/26/26 Fri 2/13/26 116 Ryan Submittal Review ( glazing exterior )5 days Mon 2/16/26 Fri 2/20/26 117 Designer Submittal Approval ( glazing exterior )10 days Mon 2/23/26 Fri 3/6/26 118 Fabrication & Delivery ( glazing exterior )12 wks Mon 3/9/26 Mon 6/1/26 119 Interior Buildout 181 days Fri 1/23/26 Tue 10/6/26 120 HS Bifold App Bay Doors 115 days Mon 4/27/26 Tue 10/6/26 121 Buyout (HS Bifold App Bay Doors)1 day Mon 4/27/26 Mon 4/27/26 122 Submittal Development (HS Bifold App Bay Doors)15 days Tue 4/28/26 Mon 5/18/26 123 Ryan Submittal Review (HS Bifold App Bay Doors)5 days Tue 5/19/26 Tue 5/26/26 124 Designer Submittal Approval (HS Bifold App Bay Doors)14 days Wed 5/27/26 Mon 6/15/26 125 Fabrication & Delivery (HS Bifold App Bay Doors)16 wks Tue 6/16/26 Tue 10/6/26 126 Light Gage Metal Studs 35 days Mon 4/27/26 Mon 6/15/26 127 Buyout ( light gage metal studs ) 1 day Mon 4/27/26 Mon 4/27/26 128 Submittal Development ( light gage metal studs )5 days Tue 4/28/26 Mon 5/4/26 129 Ryan Submittal Review ( light gage metal studs )5 days Tue 5/5/26 Mon 5/11/26 130 Designer Submittal Approval ( light gage metal studs )14 days Tue 5/12/26 Mon 6/1/26 131 Fabrication & Delivery ( light gage metal studs )10 days Tue 6/2/26 Mon 6/15/26 132 Sheetrock / Specialties 35 days Mon 4/27/26 Mon 6/15/26 133 Buyout ( sheetrock / specialties ) 1 day Mon 4/27/26 Mon 4/27/26 134 Submittal Development ( sheetrock / specialties )10 days Tue 4/28/26 Mon 5/11/26 135 Ryan Submittal Review ( sheetrock / specialties )5 days Tue 5/12/26 Mon 5/18/26 136 Designer Submittal Approval ( sheetrock / specialties )14 days Tue 5/19/26 Mon 6/8/26 137 Fabrication & Delivery ( sheetrock / specialties )1 wk Tue 6/9/26 Mon 6/15/26 138 Door Frames 90 days Fri 1/23/26 Fri 5/29/26 139 Buyout ( door frames ) 1 day Fri 1/23/26 Fri 1/23/26 140 Submittal Development ( door frames )10 days Mon 1/26/26 Fri 2/6/26 141 Ryan Submittal Review ( door frames )5 days Mon 2/9/26 Fri 2/13/26 142 Designer Submittal Approval ( door frames )14 days Mon 2/16/26 Thu 3/5/26 143 Fabrication & Delivery ( exterior door frames )12 wks Fri 3/6/26 Fri 5/29/26 144 Fabrication and Delivery ( interior Frames)12 wks Fri 3/6/26 Fri 5/29/26 145 Door Hardware 80 days Mon 4/27/26 Mon 8/17/26 146 Buyout ( door hardware ) 1 day Mon 4/27/26 Mon 4/27/26 147 Submittal Development ( door hardware )15 days Tue 4/28/26 Mon 5/18/26 148 Ryan Submittal Review ( door hardware )10 days Tue 5/19/26 Tue 6/2/26 149 Designer Submittal Approval ( door hardware )14 days Wed 6/3/26 Mon 6/22/26 150 Fabrication & Delivery ( door hardware )40 days Tue 6/23/26 Mon 8/17/26 151 Paint 45 days Mon 4/27/26 Mon 6/29/26 152 Buyout ( paint ) 1 day Mon 4/27/26 Mon 4/27/26 ID Task Name Duration Start Finish 153 Submittal Development ( paint )20 days Tue 4/28/26 Tue 5/26/26 154 Ryan Submittal Review ( paint )5 days Wed 5/27/26 Tue 6/2/26 155 Designer Submittal Approval ( paint )14 days Wed 6/3/26 Mon 6/22/26 156 Fabrication & Delivery ( paint )5 days Tue 6/23/26 Mon 6/29/26 157 Acoustical Ceilings 50 days Mon 4/27/26 Mon 7/6/26 158 Buyout ( acoustical ceilings ) 1 day Mon 4/27/26 Mon 4/27/26 159 Submittal Development ( acoustical ceilings )15 days Tue 4/28/26 Mon 5/18/26 160 Ryan Submittal Review ( acoustical ceilings )5 days Tue 5/19/26 Tue 5/26/26 161 Designer Submittal Approval ( acoustical ceilings )14 days Wed 5/27/26 Mon 6/15/26 162 Fabrication & Delivery ( acoustical ceilings )15 days Tue 6/16/26 Mon 7/6/26 163 Ceramic Tile 70 days Mon 4/27/26 Mon 8/3/26 164 Buyout ( ceramic tile ) 1 day Mon 4/27/26 Mon 4/27/26 165 Submittal Development ( ceramic tile )20 days Tue 4/28/26 Tue 5/26/26 166 Ryan Submittal Review ( ceramic tile )5 days Wed 5/27/26 Tue 6/2/26 167 Designer Submittal Approval ( ceramic tile )14 days Wed 6/3/26 Mon 6/22/26 168 Fabrication & Delivery ( ceramic tile )6 wks Tue 6/23/26 Mon 8/3/26 169 Millwork 65 days Mon 4/27/26 Mon 7/27/26 170 Buyout ( millwork ) 1 day Mon 4/27/26 Mon 4/27/26 171 Submittal Development ( millwork )15 days Tue 4/28/26 Mon 5/18/26 172 Ryan Submittal Review ( millwork )5 days Tue 5/19/26 Tue 5/26/26 173 Designer Submittal Approval ( millwork )14 days Wed 5/27/26 Mon 6/15/26 174 Fabrication & Delivery ( millwork )6 wks Tue 6/16/26 Mon 7/27/26 175 Flooring 65 days Mon 4/27/26 Mon 7/27/26 176 Buyout ( flooring ) 1 day Mon 4/27/26 Mon 4/27/26 177 Submittal Development ( flooring )20 days Tue 4/28/26 Tue 5/26/26 178 Ryan Submittal Review ( flooring )5 days Wed 5/27/26 Tue 6/2/26 179 Designer Submittal Approval ( flooring )14 days Wed 6/3/26 Mon 6/22/26 180 Fabrication & Delivery ( flooring )5 wks Tue 6/23/26 Mon 7/27/26 181 Specialties 70 days Mon 4/27/26 Mon 8/3/26 182 Toilet Partitions / Specialties / FE / FE Cabinets 70 days Mon 4/27/26 Mon 8/3/26 183 Buyout ( toilet partitions / specialties ) 1 day Mon 4/27/26 Mon 4/27/26 184 Submittal Development ( toilet partitions / specialties )20 days Tue 4/28/26 Tue 5/26/26 185 Ryan Submittal Review ( toilet partitions / specialties )5 days Wed 5/27/26 Tue 6/2/26 186 Designer Submittal Approval ( toilet partitions / specialties )14 days Wed 6/3/26 Mon 6/22/26 187 Fabrication & Delivery ( toilet partitions / specialties )6 wks Tue 6/23/26 Mon 8/3/26 188 Interior Signage 70 days Mon 4/27/26 Mon 8/3/26 189 Buyout ( interior signage ) 1 day Mon 4/27/26 Mon 4/27/26 190 Submittal Development ( interior signage )30 days Tue 4/28/26 Tue 6/9/26 191 Ryan Submittal Review ( interior signage )5 days Wed 6/10/26 Tue 6/16/26 192 Designer Submittal Approval ( interior signage )14 days Wed 6/17/26 Mon 7/6/26 193 Fabrication & Delivery ( interior signage )4 wks Tue 7/7/26 Mon 8/3/26 194 Fire Sprinkler 55 days Mon 4/27/26 Mon 7/13/26 195 Buyout ( fire sprinkler ) 1 day Mon 4/27/26 Mon 4/27/26 196 Submittal Development ( fire sprinkler )15 days Tue 4/28/26 Mon 5/18/26 197 Ryan Submittal Review ( fire sprinkler )5 days Tue 5/19/26 Tue 5/26/26 198 Designer Submittal Approval ( fire sprinkler )14 days Wed 5/27/26 Mon 6/15/26 199 Fire Marshall/City Approval 15 days Tue 6/16/26 Mon 7/6/26 200 Fabrication & Delivery ( fire sprinkler )5 days Tue 7/7/26 Mon 7/13/26 201 Plumbing / Mechanical 90 days Mon 4/27/26 Mon 8/31/26 202 Plumbing Piping / Accessories 35 days Mon 4/27/26 Mon 6/15/26 203 Buyout ( plumbing piping / acc ) 1 day Mon 4/27/26 Mon 4/27/26 ID Task Name Duration Start Finish 204 Submittal Development ( plumbing piping / acc )10 days Tue 4/28/26 Mon 5/11/26 205 Ryan Submittal Review ( plumbing piping / acc )5 days Tue 5/12/26 Mon 5/18/26 206 Designer Submittal Approval ( plumbing piping / acc )14 days Tue 5/19/26 Mon 6/8/26 207 Fabrication & Delivery ( plumbing piping / acc )1 wk Tue 6/9/26 Mon 6/15/26 208 Plumbing Fixtures 60 days Mon 4/27/26 Mon 7/20/26 209 Buyout ( plumbing fixtures ) 1 day Mon 4/27/26 Mon 4/27/26 210 Submittal Development ( plumbing fixtures )20 days Tue 4/28/26 Tue 5/26/26 211 Ryan Submittal Review ( plumbing fixtures )5 days Wed 5/27/26 Tue 6/2/26 212 Designer Submittal Approval ( plumbing fixtures )14 days Wed 6/3/26 Mon 6/22/26 213 Fabrication & Delivery ( plumbing fixtures )4 wks Tue 6/23/26 Mon 7/20/26 214 Plumbing Insulation 35 days Mon 4/27/26 Mon 6/15/26 215 Buyout ( plumbing insulation ) 1 day Mon 4/27/26 Mon 4/27/26 216 Submittal Development ( plumbing insulation )10 days Tue 4/28/26 Mon 5/11/26 217 Ryan Submittal Review ( plumbing insulation )5 days Tue 5/12/26 Mon 5/18/26 218 Designer Submittal Approval ( plumbing insulation )14 days Tue 5/19/26 Mon 6/8/26 219 Fabrication & Delivery ( plumbing insulation )1 wk Tue 6/9/26 Mon 6/15/26 220 ERVs 90 days Mon 4/27/26 Mon 8/31/26 221 Buyout ( ERVs ) 1 day Mon 4/27/26 Mon 4/27/26 222 Submittal Development ( ERVs )10 days Tue 4/28/26 Mon 5/11/26 223 Ryan Submittal Review ( ERVs )5 days Tue 5/12/26 Mon 5/18/26 224 Designer Submittal Approval ( ERVs )14 days Tue 5/19/26 Mon 6/8/26 225 Fabrication & Delivery ( ERVs )12 wks Tue 6/9/26 Mon 8/31/26 226 Water Heaters 70 days Mon 4/27/26 Mon 8/3/26 227 Buyout ( Water Heaters ) 1 day Mon 4/27/26 Mon 4/27/26 228 Submittal Development ( Water Heaters ) 10 days Tue 4/28/26 Mon 5/11/26 229 Ryan Submittal Review ( Water Heaters ) 5 days Tue 5/12/26 Mon 5/18/26 230 Designer Submittal Approva ( Water Heaters ) 14 days Tue 5/19/26 Mon 6/8/26 231 Fabrication & Delivery ( Water Heaters ) 8 wks Tue 6/9/26 Mon 8/3/26 232 Furnace 60 days Mon 4/27/26 Mon 7/20/26 233 Buyout ( Furnace ) 1 day Mon 4/27/26 Mon 4/27/26 234 Submittal Development ( Furnace )10 days Tue 4/28/26 Mon 5/11/26 235 Ryan Submittal Review ( Furnace )5 days Tue 5/12/26 Mon 5/18/26 236 Designer Submittal Approval ( Furnace )14 days Tue 5/19/26 Mon 6/8/26 237 Fabrication & Delivery ( Furnace )6 wks Tue 6/9/26 Mon 7/20/26 238 Heat Pumps 90 days Mon 4/27/26 Mon 8/31/26 239 Buyout ( Heat Pumps ) 1 day Mon 4/27/26 Mon 4/27/26 240 Submittal Development ( Heat Pumps )10 days Tue 4/28/26 Mon 5/11/26 241 Ryan Submittal Review ( Heat Pumps )5 days Tue 5/12/26 Mon 5/18/26 242 Designer Submittal Approval ( Heat Pumps )14 days Tue 5/19/26 Mon 6/8/26 243 Fabrication & Delivery ( Heat Pumps )12 wks Tue 6/9/26 Mon 8/31/26 244 Exhaust Fans 90 days Mon 4/27/26 Mon 8/31/26 245 Buyout ( Exhaust Fans ) 1 day Mon 4/27/26 Mon 4/27/26 246 Submittal Development ( Exhaust Fans )10 days Tue 4/28/26 Mon 5/11/26 247 Ryan Submittal Review ( Exhaust Fans )5 days Tue 5/12/26 Mon 5/18/26 248 Designer Submittal Approval ( Exhaust Fans )14 days Tue 5/19/26 Mon 6/8/26 249 Fabrication & Delivery ( Exhaust Fans )12 wks Tue 6/9/26 Mon 8/31/26 250 Kitchen Hood 90 days Mon 4/27/26 Mon 8/31/26 251 Buyout ( Kitchen Hood ) 1 day Mon 4/27/26 Mon 4/27/26 252 Submittal Development ( Kitchen Hood )10 days Tue 4/28/26 Mon 5/11/26 253 Ryan Submittal Review ( Kitchen Hood )5 days Tue 5/12/26 Mon 5/18/26 254 Designer Submittal Approval ( Kitchen Hood )14 days Tue 5/19/26 Mon 6/8/26 ID Task Name Duration Start Finish 255 Fabrication & Delivery ( Kitchen Hood )12 wks Tue 6/9/26 Mon 8/31/26 256 VRF 90 days Mon 4/27/26 Mon 8/31/26 257 Buyout ( VRF ) 1 day Mon 4/27/26 Mon 4/27/26 258 Submittal Development ( VRF )10 days Tue 4/28/26 Mon 5/11/26 259 Ryan Submittal Review ( VRF )5 days Tue 5/12/26 Mon 5/18/26 260 Designer Submittal Approval ( VRF )14 days Tue 5/19/26 Mon 6/8/26 261 Fabrication & Delivery ( VRF )12 wks Tue 6/9/26 Mon 8/31/26 262 Split System AC 40 days Mon 4/27/26 Mon 6/22/26 263 Buyout ( Split System AC ) 1 day Mon 4/27/26 Mon 4/27/26 264 Submittal Development ( Split System AC )10 days Tue 4/28/26 Mon 5/11/26 265 Ryan Submittal Review ( Split System AC )5 days Tue 5/12/26 Mon 5/18/26 266 Designer Submittal Approval ( Split System AC )14 days Tue 5/19/26 Mon 6/8/26 267 Fabrication & Delivery ( Split System AC )2 wks Tue 6/9/26 Mon 6/22/26 268 Gas-Fired Radiant Heaters 60 days Mon 4/27/26 Mon 7/20/26 269 Buyout ( Gas-Fired Radiant Heaters ) 1 day Mon 4/27/26 Mon 4/27/26 270 Submittal Development ( Gas-Fired Radiant Heaters )10 days Tue 4/28/26 Mon 5/11/26 271 Ryan Submittal Review ( Gas-Fired Radiant Heaters )5 days Tue 5/12/26 Mon 5/18/26 272 Designer Submittal Approval ( Gas-Fired Radiant Heaters )14 days Tue 5/19/26 Mon 6/8/26 273 Fabrication & Delivery ( Gas-Fired Radiant Heaters )6 wks Tue 6/9/26 Mon 7/20/26 274 Gas-Fired Makeup Air Blower Coil (MAU)90 days Mon 4/27/26 Mon 8/31/26 275 Buyout ( Gas-Fired MAU ) 1 day Mon 4/27/26 Mon 4/27/26 276 Submittal Development ( Gas-Fired MAU )10 days Tue 4/28/26 Mon 5/11/26 277 Ryan Submittal Review ( Gas-Fired MAU )5 days Tue 5/12/26 Mon 5/18/26 278 Designer Submittal Approval ( Gas-Fired MAU )14 days Tue 5/19/26 Mon 6/8/26 279 Fabrication & Delivery ( Gas-Fired MAU )12 wks Tue 6/9/26 Mon 8/31/26 280 Ductwork 40 days Mon 4/27/26 Mon 6/22/26 281 Buyout ( ductwork ) 1 day Mon 4/27/26 Mon 4/27/26 282 Submittal Development ( ductwork )10 days Tue 4/28/26 Mon 5/11/26 283 Ryan Submittal Review ( ductwork )5 days Tue 5/12/26 Mon 5/18/26 284 Designer Submittal Approval ( ductwork )14 days Tue 5/19/26 Mon 6/8/26 285 Fabrication & Delivery ( ductwork )10 days Tue 6/9/26 Mon 6/22/26 286 Duct Insulation 40 days Mon 4/27/26 Mon 6/22/26 287 Buyout ( duct insulation ) 1 day Mon 4/27/26 Mon 4/27/26 288 Submittal Development ( duct insulation )10 days Tue 4/28/26 Mon 5/11/26 289 Ryan Submittal Review ( duct insulation )5 days Tue 5/12/26 Mon 5/18/26 290 Designer Submittal Approval ( duct insulation )14 days Tue 5/19/26 Mon 6/8/26 291 Fabrication & Delivery ( duct insulation )10 days Tue 6/9/26 Mon 6/22/26 292 HVLS Fans (App Bay)70 days Mon 4/27/26 Mon 8/3/26 293 Buyout ( HVLS Fans ) 1 day Mon 4/27/26 Mon 4/27/26 294 Submittal Development ( HVLS Fans )30 days Tue 4/28/26 Tue 6/9/26 295 Ryan Submittal Review ( HVLS Fans )5 days Wed 6/10/26 Tue 6/16/26 296 Designer Submittal Approval ( HVLS Fans )14 days Wed 6/17/26 Mon 7/6/26 297 Fabrication & Delivery ( HVLS Fans )4 wks Tue 7/7/26 Mon 8/3/26 298 Grilles / Diffusers 40 days Mon 4/27/26 Mon 6/22/26 299 Buyout ( grilles / diffusers ) 1 day Mon 4/27/26 Mon 4/27/26 300 Submittal Development ( grilles / diffusers )10 days Tue 4/28/26 Mon 5/11/26 301 Ryan Submittal Review ( grilles / diffusers )5 days Tue 5/12/26 Mon 5/18/26 302 Designer Submittal Approval ( grilles / diffusers )14 days Tue 5/19/26 Mon 6/8/26 303 Fabrication & Delivery ( grilles / diffusers )10 days Tue 6/9/26 Mon 6/22/26 304 Controls Mechanical 70 days Mon 4/27/26 Mon 8/3/26 305 Buyout ( controls mechanical ) 1 day Mon 4/27/26 Mon 4/27/26 ID Task Name Duration Start Finish 306 Submittal Development ( controls mechanical )20 days Tue 4/28/26 Tue 5/26/26 307 Ryan Submittal Review ( controls mechanical )5 days Wed 5/27/26 Tue 6/2/26 308 Designer Submittal Approval ( controls mechanical )14 days Wed 6/3/26 Mon 6/22/26 309 Fabrication & Delivery ( controls mechanical )6 wks Tue 6/23/26 Mon 8/3/26 310 Electrical 67 days Mon 4/27/26 Wed 7/29/26 311 Generator Docking Station 67 days Mon 4/27/26 Wed 7/29/26 312 Buyout ( Generator Docking Station ) 1 day Mon 4/27/26 Mon 4/27/26 313 Submittal Development 10 days Tue 4/28/26 Thu 5/28/26 314 Ryan Submittal Review 5 days Fri 5/29/26 Thu 6/4/26 315 Designer Submittal Review 14 days Fri 6/5/26 Wed 6/24/26 316 Fabrication & Delivery 5 wks Thu 6/25/26 Wed 7/29/26 317 Pipe / Wiring 40 days Mon 4/27/26 Mon 6/22/26 318 Buyout ( elec pipe / wiring ) 1 day Mon 4/27/26 Mon 4/27/26 319 Submittal Development ( elec pipe / wiring )10 days Tue 4/28/26 Mon 5/11/26 320 Ryan Submittal Review ( elec pipe / wiring )5 days Tue 5/12/26 Mon 5/18/26 321 Designer Submittal Approval ( elec pipe / wiring )14 days Tue 5/19/26 Mon 6/8/26 322 Fabrication & Delivery ( elec pipe / wiring )10 days Tue 6/9/26 Mon 6/22/26 323 Light Fixtures 60 days Mon 4/27/26 Mon 7/20/26 324 Buyout ( light fixtures ) 1 day Mon 4/27/26 Mon 4/27/26 325 Submittal Development ( light fixtures )15 days Tue 4/28/26 Mon 5/18/26 326 Ryan Submittal Review ( light fixtures )5 days Tue 5/19/26 Tue 5/26/26 327 Designer Submittal Approval ( light fixtures )14 days Wed 5/27/26 Mon 6/15/26 328 Fabrication & Delivery ( light fixtures )5 wks Tue 6/16/26 Mon 7/20/26 329 Fire Alarm 50 days Mon 4/27/26 Mon 7/6/26 330 Buyout ( fire alarm ) 1 day Mon 4/27/26 Mon 4/27/26 331 Submittal Development ( fire alarm )10 days Tue 4/28/26 Mon 5/11/26 332 Ryan Submittal Review ( fire alarm )5 days Tue 5/12/26 Mon 5/18/26 333 Designer Submittal Approval ( fire alarm )14 days Tue 5/19/26 Mon 6/8/26 334 Fire Marshall/City Approval 10 days Tue 6/9/26 Mon 6/22/26 335 Fabrication & Delivery ( fire alarm )2 wks Tue 6/23/26 Mon 7/6/26 336 Building Automation Systems 55 days Mon 4/27/26 Mon 7/13/26 337 Buyout ( BAS ) 1 day Mon 4/27/26 Mon 4/27/26 338 Submittal Development ( BAS )10 days Tue 4/28/26 Mon 5/11/26 339 Ryan Submittal Review ( BAS )5 days Tue 5/12/26 Mon 5/18/26 340 Designer Submittal Approval ( BAS )14 days Tue 5/19/26 Mon 6/8/26 341 Fabrication & Delivery ( BAS )25 days Tue 6/9/26 Mon 7/13/26 342 Project Milestones 203 days Fri 2/27/26 Mon 12/14/26 343 Construction Documents Complete 0 days Fri 2/27/26 Fri 2/27/26 344 Full Buyout Under Contract 0 days Fri 4/24/26 Fri 4/24/26 345 Construction Start 0 days Mon 4/27/26 Mon 4/27/26 346 Building Enclosure Renovations Complete 0 days Tue 12/8/26 Tue 12/8/26 347 Site Work Complete 0 days Wed 9/9/26 Wed 9/9/26 348 Building Finishes Complete 0 days Fri 12/11/26 Fri 12/11/26 349 Substantial Completion 0 days Mon 12/14/26 Mon 12/14/26 350 Owner Move In 0 days Mon 12/14/26 Mon 12/14/26 351 Construction Process 180 days Mon 4/27/26 Fri 1/8/27 352 Mobilization 1 day Mon 4/27/26 Mon 4/27/26 353 Mobilize 1 day Mon 4/27/26 Mon 4/27/26 354 Sitework 95 days Tue 4/28/26 Wed 9/9/26 355 Install Tree Protection 1 day Tue 4/28/26 Tue 4/28/26 356 Remove Trees 1 day Wed 4/29/26 Wed 4/29/26 ID Task Name Duration Start Finish 357 West Parking Lot 45 days Thu 4/30/26 Fri 7/3/26 358 Demo Pavement, Curb and Gutter 4 days Thu 4/30/26 Tue 5/5/26 359 Cut / Export 6'' of Subgrade 3 days Wed 5/6/26 Fri 5/8/26 360 Import & Place 6'' Aggregate Subbase 2 days Mon 5/11/26 Tue 5/12/26 361 Fine Grade Pavement & Pour Prep - Sequence 1 2 days Wed 5/13/26 Thu 5/14/26 362 Pavement, Curb and Gutter Pour - Sequence 1 1 day Tue 6/30/26 Tue 6/30/26 363 Fine Grade Pavement & Pour Prep - Sequence 2 2 days Wed 7/1/26 Thu 7/2/26 364 Pavement, Curb and Gutter Pour - Sequence 2 1 day Fri 7/3/26 Fri 7/3/26 365 East Parking Lot 15 days Mon 7/6/26 Fri 7/24/26 366 Demo Pavement, Curb and Gutter 4 days Mon 7/6/26 Thu 7/9/26 367 Cut / Export 6'' of Subgrade 3 days Fri 7/10/26 Tue 7/14/26 368 Import & Place 6'' Aggregate Subbase 2 days Wed 7/15/26 Thu 7/16/26 369 Fine Grade Pavement & Pour Prep - Sequence 3 2 days Fri 7/17/26 Mon 7/20/26 370 Pavement, Curb and Gutter Pour - Sequence 3 1 day Tue 7/21/26 Tue 7/21/26 371 Fine Grade Pavement & Pour Prep - Sequence 4 2 days Wed 7/22/26 Thu 7/23/26 372 Pavement, Curb and Gutter Pour - Sequence 4 1 day Fri 7/24/26 Fri 7/24/26 373 Remove and Replace Sidewalks - West 10 days Tue 4/28/26 Mon 5/11/26 374 Remove and Replace Sidewalks - along SE LA Grant Pkwy 8 days Tue 5/12/26 Thu 5/21/26 375 Remove and Replace Sidewalks - East/Courtyard 10 days Tue 5/5/26 Mon 5/18/26 376 North Site 35 days Wed 4/29/26 Wed 6/17/26 377 Demo Existing A/C Condensor Pad 1 day Wed 4/29/26 Wed 4/29/26 378 Regrade North Site due to Drainage Issues 5 days Tue 6/9/26 Mon 6/15/26 379 Install New 8'' Storm Line from Central Downspout 2 days Tue 6/16/26 Wed 6/17/26 380 Dig, Form and Pour New Stoop 1 day Tue 6/16/26 Tue 6/16/26 381 Form and Pour New A/C Condensor Pad 2 days Tue 6/16/26 Wed 6/17/26 382 Install New Sanitary Line from App Bay/Gross Decon (120 LF)7 days Wed 4/29/26 Thu 5/7/26 383 Retrofit Existing Pole Mounted Site Light Fixtures 3 days Mon 7/27/26 Wed 7/29/26 384 Install Pavement Markings 1 day Mon 7/27/26 Mon 7/27/26 385 SUDAS Planting Window Hold 2 days Mon 8/24/26 Tue 8/25/26 386 Landscaping 10 days Wed 8/26/26 Wed 9/9/26 387 Exterior Building Finishes 124 days Tue 4/28/26 Tue 10/20/26 388 Remove and Replace Storefront and Curtain Wall Windows 20 days Tue 6/2/26 Mon 6/29/26 389 Tuck Point Brick / Replace Limestone Base 25 days Tue 6/23/26 Mon 7/27/26 390 Exterior Building Wash 5 days Tue 7/28/26 Mon 8/3/26 391 Sandblast and Scrape West Entrance Tube Steel Structure 2 days Tue 4/28/26 Wed 4/29/26 392 Repaint West Entrance Steel Structure 1 day Tue 6/30/26 Tue 6/30/26 393 Install ACM Metal Panels at West Entrnace 5 days Wed 7/1/26 Tue 7/7/26 394 Install Metal Panel Soffit at West Entrance 2 days Wed 7/8/26 Thu 7/9/26 395 Replace Gyp Soffits adjacent to West Entrance 5 days Fri 7/10/26 Thu 7/16/26 396 Remove and Replace Gutters and Downspouts 7 days Tue 8/4/26 Wed 8/12/26 397 Exterior OH & Bifold Doors & Man doors 10 days Wed 10/7/26 Tue 10/20/26 398 Demo Old Steel Deck and Stairs 5 days Tue 4/28/26 Mon 5/4/26 399 Excavate and Pour New Deck Spread Footings 3 days Tue 7/14/26 Thu 7/16/26 400 Erect New Deck, Stairs and Railing 4 days Tue 7/21/26 Fri 7/24/26 401 Demo and Replace Trash Enclosure Masonry Walls 8 days Tue 5/19/26 Fri 5/29/26 402 Construct New Monument Sign on Existing Footing 3 days Wed 9/9/26 Fri 9/11/26 403 Interior Buildout 151 days Tue 4/28/26 Fri 11/27/26 404 Relocate FFE 5 days Tue 4/28/26 Mon 5/4/26 405 Community Development Renovation 134 days Tue 5/5/26 Tue 11/10/26 406 Demo HVAC & Overhead MEP 5 days Tue 5/5/26 Mon 5/11/26 407 Demo RR Specialties 2 days Tue 5/5/26 Wed 5/6/26 ID Task Name Duration Start Finish 408 Demo Ceiling Finishes 4 days Tue 5/12/26 Fri 5/15/26 409 Demo Floor Finishes 3 days Mon 5/18/26 Wed 5/20/26 410 Demo Existing Gyp. Board Walls 5 days Thu 5/21/26 Thu 5/28/26 411 Above-Ceiling Plumbing Rough-In 10 days Fri 5/29/26 Thu 6/11/26 412 Above-Ceiling HVAC Rougn-In 10 days Fri 5/29/26 Thu 6/11/26 413 Install New HVAC Equipment 15 days Tue 9/1/26 Tue 9/22/26 414 Above-Ceiling Inspections 1 day Wed 9/23/26 Wed 9/23/26 415 Install Door Frames 5 days Fri 6/19/26 Thu 6/25/26 416 Interior Framing 8 days Tue 6/16/26 Thu 6/25/26 417 Modify Existing Fire Sprinkler Piping for New Room Layout 10 days Tue 7/14/26 Mon 7/27/26 418 Plumbing In-Wall Rough-In 10 days Fri 6/26/26 Thu 7/9/26 419 Electrical In-Wall Rough-In 10 days Wed 7/8/26 Tue 7/21/26 420 Low Voltage / Fire Alarm In-Wall Rough-In 10 days Mon 7/20/26 Fri 7/31/26 421 In-Wall Inspections 1 day Mon 8/3/26 Mon 8/3/26 422 Install In-Wall Backing & Blocking 4 days Tue 8/4/26 Fri 8/7/26 423 Install Drywall 8 days Mon 8/10/26 Wed 8/19/26 424 Tape and Finish Drywall 10 days Thu 8/13/26 Wed 8/26/26 425 Painting Walls 5 days Thu 8/27/26 Wed 9/2/26 426 Tile Restrooms - floors & walls 12 days Thu 9/3/26 Mon 9/21/26 427 Install Ceiling Grid 7 days Tue 9/22/26 Wed 9/30/26 428 Install Ceiling Tiles 4 days Thu 10/1/26 Tue 10/6/26 429 Restroom Accessories 1 day Tue 9/22/26 Tue 9/22/26 430 Install Lobby Floor Tile 8 days Tue 9/15/26 Thu 9/24/26 431 Fire Sprinkler Trim-Out 5 days Thu 10/1/26 Wed 10/7/26 432 MEP Ceiling Trim-Out 7 days Fri 10/2/26 Mon 10/12/26 433 Millwork & Specialities 15 days Wed 10/7/26 Tue 10/27/26 434 Install Flooring & Base 10 days Wed 10/28/26 Tue 11/10/26 435 Install Signage 3 days Thu 9/3/26 Tue 9/8/26 436 Doors and Hardware 5 days Thu 9/3/26 Thu 9/10/26 437 Fire Dept. Renovation 143 days Tue 5/5/26 Mon 11/23/26 438 Demo HVAC & Overhead MEP 10 days Tue 5/5/26 Mon 5/18/26 439 Demo RR Specialties 4 days Tue 5/5/26 Fri 5/8/26 440 Demo Ceiling Finishes 3 days Tue 5/19/26 Thu 5/21/26 441 Demo Floor Finishes 3 days Fri 5/22/26 Wed 5/27/26 442 Demo Existing Gyp. Board Walls 5 days Thu 5/28/26 Wed 6/3/26 443 Demo Non-Load Bearing CMU Walls 3 days Thu 5/28/26 Mon 6/1/26 444 Above-Ceiling Plumbing Rough-In 7 days Tue 6/2/26 Wed 6/10/26 445 Install New HVAC Equipment 7 days Tue 6/23/26 Wed 7/1/26 446 Above-Ceiling HVAC Rougn-In 7 days Thu 6/11/26 Fri 6/19/26 447 Above-Ceiling Inspections 1 day Mon 6/22/26 Mon 6/22/26 448 Interior Framing 5 days Thu 7/2/26 Wed 7/8/26 449 Install Door Frames 5 days Thu 7/9/26 Wed 7/15/26 450 Plumbing In-Wall Rough-In 5 days Fri 7/17/26 Thu 7/23/26 451 Electrical In-Wall Rough-In 5 days Wed 7/22/26 Tue 7/28/26 452 Low Voltage/Fire Alarm In-Wall Rough-In 5 days Mon 7/27/26 Fri 7/31/26 453 In-Wall Inspections 1 day Mon 8/3/26 Mon 8/3/26 454 Install In-Wall Backing & Blocking 3 days Tue 8/4/26 Thu 8/6/26 455 Install Drywall 5 days Fri 8/7/26 Thu 8/13/26 456 Tape and Finish Drywall 5 days Fri 8/14/26 Thu 8/20/26 457 Painting Walls 10 days Fri 8/21/26 Thu 9/3/26 458 Tile Restrooms - floors & walls 16 days Fri 9/4/26 Mon 9/28/26 ID Task Name Duration Start Finish 459 Install Restroom Accessories 2 days Fri 9/4/26 Tue 9/8/26 460 Install Ceiling Grid 7 days Tue 9/29/26 Wed 10/7/26 461 Fire Sprinkler Trim-Out 5 days Thu 10/8/26 W ed 10/14/26 462 MEP Ceiling Trim-Out 7 days Thu 10/8/26 Fri 10/16/26 463 Install Ceiling Tiles 4 days Wed 10/14/26 Mon 10/19/26 464 Millwork & Specialities 15 days Tue 10/20/26 Mon 11/9/26 465 Install Flooring & Base 10 days Tue 11/10/26 Mon 11/23/26 466 Install Signage 3 days Fri 9/4/26 Wed 9/9/26 467 Doors and Hardware 4 days Thu 7/16/26 Tue 7/21/26 468 Install Fitness Center Equipment 2 days Tue 11/17/26 W ed 11/18/26 469 FD Medium Decon / Locker Room Area 39 days Thu 5/28/26 Tue 7/21/26 470 Install Shoring for Lintel W ork 3 days Thu 5/28/26 Mon 6/1/26 471 Demo Load-Bearing CMU Walls 3 days Tue 6/2/26 Thu 6/4/26 472 Demo SOG for Columns, UG Plumbing & CMU Thickened Slabs 3 days Fri 6/5/26 Tue 6/9/26 473 Install Lintels & Columns 4 days Tue 6/16/26 Fri 6/19/26 474 Install Underground Plumbing 5 days Mon 6/22/26 Fri 6/26/26 475 Pour SOG & Thickened Slabs 3 days Mon 6/29/26 Wed 7/1/26 476 CMU Wall Layout and Construction 8 days Tue 7/7/26 Thu 7/16/26 477 Interior Framing 5 days Tue 7/7/26 Mon 7/13/26 478 Install Door Frames 3 days Fri 7/17/26 Tue 7/21/26 479 Apparatus Bay Work 63 days Tue 5/19/26 Fri 8/14/26 480 FD Fitness, Turnout & Gross Decon Area 32 days Tue 5/19/26 Thu 7/2/26 481 Demo Southern Most Bay Existing SOG 3 days Tue 5/19/26 Thu 5/21/26 482 Remove Trench Drain and Cap Sanitary Line 1 day Thu 5/21/26 Thu 5/21/26 483 Install Underground Plumbing 4 days Fri 5/22/26 Thu 5/28/26 484 SOG Prep 1 day Fri 5/29/26 Fri 5/29/26 485 Pour SOG 2 days Mon 6/1/26 Tue 6/2/26 486 Layout and Install CMU walls 15 days Wed 6/10/26 Tue 6/30/26 487 Install Door Frames 2 days Wed 7/1/26 Thu 7/2/26 488 Powerwash/Clean App Bay Structure 3 days Wed 6/3/26 Fri 6/5/26 489 Tape & Prep App Bay Structure for Drywall Paint 5 days Mon 6/8/26 Fri 6/12/26 490 Drywall Paint App Bay Structure 5 days Mon 6/15/26 Fri 6/19/26 491 Install CFMF Joists & OSB Sheathing Lid 5 days Tue 7/28/26 Mon 8/3/26 492 Modify Existing Fire Sprinkler System for New Rooms 4 days Wed 7/1/26 Mon 7/6/26 493 Install App Bay MEP Overhead 5 days Wed 7/1/26 Tue 7/7/26 494 Prep/Grind App Bay Floor for Resealing 5 days Tue 8/4/26 Mon 8/10/26 495 Caulk and Reseal App Bay Floor 4 days Tue 8/11/26 Fri 8/14/26 496 Final Clean 3 days Tue 11/24/26 Fri 11/27/26 497 Project Close Out 75 days Wed 9/23/26 Fri 1/8/27 498 Exterior Punchlist/Completion 5 days Wed 10/21/26 Tue 10/27/26 499 MEP Startup 5 days Wed 9/23/26 Tue 9/29/26 500 City IT Network & Equipment 20 days Wed 9/23/26 Tue 10/20/26 501 MEP Test and Balance 10 days Wed 10/14/26 Tue 10/27/26 502 MEP Commissioning 10 days Wed 10/28/26 Tue 11/10/26 503 Weather Days (Exterior Work)5 days Wed 10/28/26 Tue 11/3/26 504 Interior Punchlist/Completion 7 days Mon 11/30/26 Tue 12/8/26 505 TCO Inspections 3 days Wed 12/9/26 Fri 12/11/26 506 TCO/Substantial Completion 1 day Mon 12/14/26 Mon 12/14/26 507 Owner FFE 11 days Tue 12/15/26 W ed 12/30/26 508 Final CO 1 day Thu 12/31/26 Thu 12/31/26 509 Owner Move In 5 days Mon 1/4/27 Fri 1/8/27 CITY OF WAUKEE OPN PROJECT NO. 25821000 EXISTING PD/FD BLDG RENOVATION EARLY BID PACKAGE BID PACKAGE #01 – EXTERIOR GLASS & GLAZING 01 12 00.01 - 1 SECTION 01 12 00.01 BID PACKAGE #01 – EXTERIOR GLASS & GLAZING PART 1 - GENERAL 1.01 SECTION INCLUDES A. Specifications Included In This Bid Package B. Bid Package Schedule C. Bid Package Scope of Work D. Bid Package Unit Prices E. Bid Package Alternates 1.02 SPECIFICATIONS INCLUDED IN THIS BID PACKAGE A. Division 00 – Procurement and Contracting Requirements Complete B. Division 01 – General Requirements Complete C. Division 07 – Thermal and Moisture Protection 1. 07 27 13 – Flexible Flashing As Described Below 2. 07 62 00 – Sheet Metal Flashing and Trim As Described Below 3. 07 92 00.01 – Joint Sealants – BP#01 Exterior Glass & Glazing Complete 4. 07 84 00.01 – Firestopping – BP#01 Exterior Glass & Glazing Complete D. Division 08 – Openings 1. 08 41 13 – Aluminum-Framed Storefronts Complete 2. 08 44 13 – Glazed Aluminum Curtainwalls Complete 3. 08 71 00.01 – Door Hardware – BP#01 Exterior Glass & Glazing Complete 4. 08 80 00.01 – Glazing – BP#01 Exterior Glass & Glazing Complete 1.03 SCHEDULE A. Successful bidders shall begin the Work on receipt of the Notice to Proceed and shall complete work this scope of work no later than June 29th, 2026. 1. Submittals due to Ryan Co. no later than: February 13th, 2026. 2. Submittals approved by Design Team no later than: March 6th, 2026. 3. Delivery of materials to the job site no later than: June 1, 2026. 4. Removal and replacement of existing glazing systems start no later than: June 2, 2026. 5. Completion of this scope of work no later than June 29th, 2026. B. See 01 3210 CPM schedule. 1.04 SCOPE OF WORK A. Furnish and install all exterior glass, glazing, storefront, curtainwall systems and associated hardware in accordance with contract documents and below inclusions. B. Inclusions 1. Bid Package Contractor responsible for removal and disposal of existing exterior glazing system. Construction Manager will provide dumpsters for demolition disposal. 2. Bid Package Contractor responsible for temporary protection of any openings created by the removal and replacement of the exterior glazing package to ensure all openings are covered each day in a secure manner. 3. Furnish and install all caulking and sealants at all locations integral with or abutting the finished work of this bid package. Caulking shall be installed as required for water EXHIBIT C - BID PACKAGE SCOPE OF WORK CITY OF WAUKEE OPN PROJECT NO. 25821000 EXISTING PD/FD BLDG RENOVATION EARLY BID PACKAGE BID PACKAGE #01 – EXTERIOR GLASS & GLAZING 01 12 00.01 - 2 tightness and installed with attention to aesthetics. Include exterior and interior caulking/sealants. 4. Bid Package Contractor is to include firestopping, firesafing, and UL assemblies as necessary through rated assemblies for this Bid Package scope. If not rated areas, all penetrations through assemblies shall be caulked for acoustical purposes. 5. Bid Package Contractor to supply and install necessary insulation, or spandrel systems within curtain wall / storefront systems per contract documents. 6. Filling any perimeter window cavities with insulation and sealant is the responsibility of this Bid Package Contactor. 7. Bid Package Contractor responsible for sealant/mastic below aluminum thresholds. 8. Bid Package Contractor is responsible for performing and verifying all field measurements prior to fabrication as completed work schedule allows. 9. Sheet metal shall be properly finished, lapped, fastened, and incorporated into any other components whether installed in this work package or by others requiring such to ensure the proper performance of the building’s exterior envelope. Bid Package Contractor will properly fasten and seal all sheet metal joints as required. Aluminum flashing at punched opening sills is by this Bid Package Contractor. 10. Furnish and install all flashing and break metal integral with or abutting the finished work of this bid package is by this Bid Package Contractor. 11. Aluminum flashing at mechanical louver sills by others. 12. Glazing system shop drawings shall bear the seal of a Professional Engineer. Manufacturer shop drawings shall be provided. Structural analysis including surrounding conditions, thermal analysis, and air/vapor barrier interface shall be included with shop drawing submittals. 13. Bid Package Contractor shall provide all hardware for doors, entrances and operable windows provided in the work of this bid package. Wiring of any electronic door operators or other hardware will be by others; doors and frames must be able to accept security wiring and devices. Bid Package Contractor will be required to coordinate all door hardware with General Construction Bid Package Electrical & Security Bid Package Contractor. 14. Bid Package Contractor shall include temporary locking cylinders for all exterior doors during construction. 15. Bid Package Contractor shall furnish and install all items required to be embedded into adjoining system well in advance of the main installation activities. Should it not be feasible for the items to be delivered in a timely manner so as not to delay the completion of other work, Bid Package Contractor shall explore and provide alternative devices so that the project is not delayed. If no alternatives exist, Bid Package Contractor is to immediately notify Construction Manager of the issue in writing and include the delivery schedule of such items. 16. Bid Package Contractor shall coordinate with the construction schedule and the work of other trades as they apply. Openings required by other trades are to be installed and coordinated with reveal/joint patterns and appearance, if possible. Un-noted opening locations must be approved by Construction Manager in conjunction with affected trades prior to installation. 17. Bid Package Contractor responsible for water-spray test of storefront and curtainwall per the contract documents. 18. Plastic window film by others. 19. Remove all labels/stickers from finished product. CITY OF WAUKEE OPN PROJECT NO. 25821000 EXISTING PD/FD BLDG RENOVATION EARLY BID PACKAGE BID PACKAGE #01 – EXTERIOR GLASS & GLAZING 01 12 00.01 - 3 20. A separate mobilization will be required for the demolition of the two storefront sections at the current Training Room (01 08.B2 as indicated on AD102) to coordinate schedule with the masonry bid package contractor. 21. This Bid Package Contractor responsible for the firestopping assembly complete including smoke barrier flashing, bent closure panel and backpans as shown in detail L19/A352. 1.05 BID PACKAGE UNIT PRICES A. The following unit prices shall be used to determine the cost of added or deleted work. Unit prices include the complete provision, fabrication, and installation for each item listed based solely on work in place, including all necessary appurtenances and connections required to complete the work in place, sales tax, insurance, and superintendence. Unit pricing to be provided on project bid form. 1. n/a 1.06 ALTERNATES A. n/a PART 2 - PRODUCTS – NOT USED PART 3 - EXECUTION – NOT USED END OF SECTION CITY OF WAUKEE OPN PROJECT NO. 25821000 EXISTING PD/FD BLDG RENOVATION EARLY BID PACKAGE BID PACKAGE #01 – EXTERIOR GLASS & GLAZING 01 12 00.01 - 4 EXHIBIT D - DRAWINGS ARCHITECTURAL DEMOLITION DRAWINGS AD102 DEMOLITION FLOOR PLANS ARCHITECTURAL DRAWINGS A102 FLOOR PLANS A201 EXTERIOR ELEVATIONS A352 GLAZING ELEVATIONS & DETAILS CITY OF WAUKEE EXISTING PD/FD BLDG RENOVATION OPN PROJECT NO. 25821000 EARLY BID PACKAGE TABLE OF CONTENTS – VOLUME 1 00 01 10 - 1 SECTION 00 01 10 TABLE OF CONTENTS INTRODUCTORY ITEMS DIVISION 00 – INTRODUCTORY ITEMS 00 00 00 Cover OPN 00 01 07 Seals Page OPN 00 01 10 Table of Contents OPN 00 11 13.01 Advertisement for Bids RYAN 00 21 13 Instruction to Bidders RYAN 00 22 13 Supplementary Instructions to Bidders RYAN 00 31 00 Available Project Information OPN Limited Hazardous Materials Report (Dated 11-13-2025) Existing Drawings (Dated 8-31-1998) 00 41 26.01 Bid Forms and Supplementary Bid Documents – Bid Package #1 RYAN 00 60 00 Project Forms RYAN 00 60 00.01 AIA A701 - Instruction to Bidders RYAN 00 60 00.02 AIA Document A132-2019 - Standard Form of Agreement RYAN 00 60 00.02.1 AIA Document A132 Exhibit A-2019 - Insurance and Bonds RYAN 00 60 00.02.2 AIA Document E202-2022 – BIM Modeling Exhibit RYAN 00 60 00.03 AIA Document A232-2019 General Conditions for Project RYAN SPECIFICATIONS DIVISION 01 -- GENERAL REQUIREMENTS 01 10 00 Summary OPN 01 12 00.00 Contract Summary – Bid Package #01 RYAN 01 12 00.01 Bid Package #01 – Exterior Glass and Glazing RYAN 01 20 00 Price and Payment Procedures OPN 01 26 00 Contract Modification Procedures RYAN 01 30 00 Administrative Requirements OPN 01 31 00 Project Management and Coordination RYAN 01 32 00 Construction Progress Documentation RYAN 01 32 10 CPM Schedule RYAN 01 32 20 Site Logistics Plan RYAN 01 40 00 Quality Requirements OPN 01 45 33 Code Required Testing and Special Inspections OPN 01 50 00 Temporary Facilities and Controls OPN 01 60 00 Product Requirements OPN 01 60 10 Substitution Procedures OPN 01 60 10.01 Substitution Request Form OPN 01 61 16 Volatile Organic Compound (VOC) Content Restrictions OPN 01 70 00 Execution and Closeout Requirements OPN 01 78 00 Closeout Submittals OPN DIVISION 07 -- THERMAL AND MOISTURE PROTECTION 07 27 13 Flexible Flashings OPN 07 62 00 Sheet Metal Flashing and Trim OPN 07 84 00.01 Firestopping OPN 07 92 00.01 Joint Sealants OPN DIVISION 08 -- OPENINGS 08 43 13 Aluminum-Framed Storefronts OPN 08 44 13 Glazed Aluminum Curtainwalls OPN 08 71 00.01 Door Hardware OPN 08 80 00.01 Glazing OPN EXHIBIT E - SPECIFICATIONS SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION$ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 1/8/2026 Holmes Murphy &Associates 2727 Grand Prairie Parkway Waukee IA 50263 Brooke Zimmer 319-896-7710 bzimmer@holmesmurphy.com Hartford Fire Insuance Company 19682 PDMPREPC Travelers Property Casualty Co.America 25674PDMPrecast,Inc. 220 SE 6th Street,Ste.100 Des Moines,IA 50309 Twin City Fire Insurance Co 29459 71755093 A X 2,000,000 X 1,000,000 X Contractual Liab 10,000 2,000,000 4,000,000 X X 91UENOD2105 1/1/2026 1/1/2027 4,000,000 A 2,000,000 X 91UENOD2106 1/1/2026 1/1/2027 B X X 10,000,000CUP8S69541825NF1/1/2026 1/1/2027 10,000,000 X 0 C X N 91WEOD2104 1/1/2026 1/1/2027 1,000,000 1,000,000 1,000,000 Project Reference:Waukee PD/FD Building Renovation Ryan Companies,owner and all persons required by contract are Additional Insureds on General Liability and Umbrella on a primary and non-contributory basis as required by written contract with the insured,per policy terms and conditions.The General Liability and Workers Compensation include a Waiver of Subrogation in favor of Additional Insureds as required by written contract with the insured,per policy terms and conditions.30 days'notice of cancellation will be provided,with 10 days'exception for non-payment of premium,per policy terms and conditions. Ryan Companies US,Inc. 111 East Grand Suite 200 Des Moines IA 50309 USA