HomeMy WebLinkAbout2015-04-06-Resolutions 15-095_Gas Main Blanket BidsTHE CITY OF WAUIME,IOWA
RESOLUTION 15-095
APPROVING GAS MAIN BLANKET BID PRICING FROM INFRASOURCE AND Q3
IN THENAMEAND BY THEAUTHORITYOF THE CITY OF WAUKEE,IONIA
WHEREAS,the City of Waukee,iowa is a duly organized mnnicipality within Dallas County;
AND,
WHEREAS,the City contracts with certain companies for gas main installation,steel gas pipe
replacement,large service line installation and repair during the construction phase of new
subdivisions in the City;AND,
WHEREAS,Waukee Public Works requested blanket bids from InfraSource and Q3 for such
services;AND,
WHEREAS,using the blanket bids,the Waukee Public Works Department computes the lower
bidder for each individual City project and contracts with the low bidder.for the work to be
completed.
NOW THEREFORE BK IT RESOLVED that the blanket bids from InfraSource and Q3,
attached hereto as Exhibits A and B,should be and the same is hereby approved.
Passed by the City Council of the City of Waukee,Iowa,and approved tins tl 6'"day of April,
2015.
illia F.Peard,Mayor
Attest:
Rebecca D.Schuett,City Clerk
ROLL CALL VOTE
Shane Blanchard
Brian Harrison
Casey L.Harvey
Shelly Hughes
Rick Peterson
AYK
X
NAY ABSENT ABSTAIN
InfriSOU ~ca
A ~UANITA SEIIVICES COD PAIIY
City of Waukee —Blanket 2015-3 6
Waukee,iowa
InfraSource Construction,LLC
2/27/20'l 5
InfraSource Construction,LLC
4033 E Morgan Road.i Ypsilanti,Ml 48197
Tel.734-434-2000 t Fax 734-434-2001
n ~uAPETA.SCIEVICm COME nhIV
Illff BSov.Fc8
A ~UANEA EER IICEE EOMPAelY
InfraSource Construction,LLC
4033 E.Morgan Road
Ypsilanti,Ml 48197
2/27/2015
City of Waukee
Attention:Dave Dezeeuw
805 University Avenue
Waukee,IA 50263
'proposal submitted via e-mail.
Ref:City of Waukee Blanket 2014
Dear Dave:
InfraSource Construction,LLC,a Quanta Services Company,is pleased to submit our proposal for the City of Waukee 2015-16
Blanket contract.We are excited by this opportunity,and we are confident that our team has the ability and experience needed
to successfully complete the scope of work,
~Pricin
Please see unit rates attached.Pricing has been provided for years 2015 and 2016,2017 will need to be negotiated upon
completion of 2016.
~0rderin
Upon submission of a specific project,pricing will conform to the pricing schedule attached to this document,Scheduling of
services is based on availability.
~Exelveivit
This contract does not obligate the City of Waukee to utilize the services of InfraSource Construction LLC under this proposal.
InfraSource Construction LLC understands and offers its services on a project basis based on the pricing scheduled contained
therein.
We thank you for this opportunity and look forward to working with you toward a successful 2014.If you have questions or
require additional information,please don't hesitate to contact Dean Digmann or myself.
Regards,
Paul Gotto
Area Manager -Midwest
InfraSource Construction,LLC
InfraSource Construction,LLC
4033 E Morgan Road.t Ypsilanti,Ml 48197
Tel.734-434-2000 t Fax 734-434-2001
A ~UANTVx 58IEYIC05 COMPANY
A ~UAlffA 5CIIYICE5 COMPANY '
Technical Clarifications
~Proposal is based on a 50 hour work week,Delays due to others may result in a change order for labor and
equipment,
Pricing is based on enevf'installation.
a De(aya caused by others or by archeologicailhazardous material discoveries may be negotiated through a change
order.
~Proposal does not include the cost of crop damage within the project boundaries.Any crop damage cost associated
with normal construction activities would be the responsibility of the others unless noted in ihe RFP.
Pricing based on any exoess fill remaining on the property where it was excavated.No haul off of excess spoil is
included and will be billed at time and material rates attached.
~Exlensive dewatering is not included,and would need to be billed accordantly.
~Proposal does noi include the cost of permitting.All permitting to be provided by others.
Proposal assumes that native fill will be used.InfraSource has included the cost to maintain the top soil from freezing
throughout the project,
~Serviice pricing based on receiving a fh"or 1e PLS Hot Tie In Unit paid for each service.
Please note we added an additional Unit to cover 2"PLS Hot Tie lns —this unit is highlighted in yellow,
e InfraSource currently maintains equipment to perform up to 4"Low pressure taps.Any other taps performed would be
subcontracted and billed at cost plus 15'/o.
~Any subcontracting and or materials purchased to be invoiced at cost (including any and all taxes,fees etc.}plus 15%.
~By passes would be project specific and priced per each at that time.
o Terms —Net 30.
Proposal does not include the cost associated with boring(trenching in rock.If rock is encountered,it will be billed at a
rate negotiated between InfraSource and the Owner.
o No Liquidated Damages will be accepted if rock is encountered,
o Milestones will need to be adjusted if rock is encountered.
Accepted By',
Customer:
By-Print;
Signature:
~Cii eiWaukee
Wi liam P.Pe d Witness —Print
Signature:
Rebecca D.Schue t
Title:Ma or Title:it Clerk
Date:
PO Number:
Date;4 06 2015
InfraSource Construction,LLC
4033 E Morgan Road.t Ypsilanti,MI 48197
Tel.734-434e2000 o Fax 734-434-2001
A ~UANTAk SsffVICCS CClfeff All Y
P
j a
I ~
P
~~
~~
~~~
~I
I ~
~P ~~
a ~a ~e
I ~
~P P ~
~P R ~~
P P P ~~
I ~
I ~
~~4 ~~
P
4
~~
~~
~0
~~
~~
00
~~
4 I ~
~~
~~
~4
4~~
~~
~~~
~P
P P ~~
~~
P P 0 ~
~~~4~
~I
~I
P P ~~
~0
P P Q ~
P
P P ~~
I4
~I
~~~
P
P
I ~I
~~~~
I ~
~~~~
~I
~~~I
I ~II
~I ~~
~~
~g ~
~~
4 I
~I
~'~
~4 ~
~~I
4 ~~~
~~
~4 $
~~j r
~~o
~~s
o ~j s
~4 I
~I
lo ~~
j ~~~I
~a
~~
~r r p ~r
4 ~4 s
J r
~r r J r r ~r
~r r r ~r
~r r r r ~r
~J I
~j ~~
~I
4 ~~~~
~4
~I'
I ol
I ~
~~~
r r r ~
r r r r
J R Q r r r r
~r r r r ~r
~r r J yr r r ~r
~J I
e
I j ~
~~4 ~
~~~~~
~~j ~
~I
~j
~'I'
~~
~~
~r J r
r ~~
R r
r
4 r %4 0 r0rr
~~
~~
II
~II
~II
li
II
'Jl II
~~'
I ~
I
t &J ~
I
i j ~
J J ~r
I
&~
~J
I
i ~~
5 ~r
P ~
o I r
~~
I o
~4~~
I ~
I I
~~~
~~
I ~~
I e ~~
P
r r
j r $r r
I ~~~
I ~e
jI
I ~~
(
I
~II
II
»~»»~~~
~a »
~»I a a
~0 ~~~~
»a
~a ~a»
~»
~'I I a ~
~a ~»a
~»a
a
~il
»
~»J '~~I '~I
~II
a
0 »
~a J»»»»»»»
»
»
»
»
»
a
»
~g I
a ~
»~
a j
a ~
~~
a j
a ~
»~
a ~
a j
~~
a ~
a ~
a ~
a j
~~
~~
~j ~
4 j»»J
»»
~»
a»J j
~a»
»
~»a
~~
~j
~j
~~»
a»
»»
~I 0™
~I
~~~
~~
»
j»~a
II II
~il
I II
I I I
~II
~Ii I I
I II
~~
I II
a ~I
~~~~
MASTER SERVICE CONTRACT
(Between City of Waukee,Iowa &Q3 CONTRACTING,INC.for performance of designated
Work at mutually agreed upon and accepted prices.)
This agreement is made April 1",2015 effective through March 3 1",2016 by and between City of
Waukee,IA 805 University Avenue Waukee,IA 50263 (Owner)and Q3 CONTRACTING,INC.3066
Spruce Street Little Canada,MN 55117 (Contractor)to perform the Work identified in Article 2.
ARTICM 1
Contract Payment.The Owner agrees fo pay Contractor for satisfactory performance of Contractor's
work a sum derived by the attached document titled City of Waukee Blanket Contract Unit Pricing 2015
(Exhibit A)or by a detailed individual Project Quote,Said work will be paid by the Owner net 30 days
trom receipt of the Contractor's invoice.
Scope of Work Conhactor agrees to commence Owner's Work herein described upon notification by
Owner and/or after receipt of a formal Work Request.Contractor will perform and complete such Work
under general directions of Owner in accord with Owners*schedule.
Owner shalt furnish materials.Contractor shall furnish all equipment and labor necessary to complete the
Work outlined in this agreement.
The Work includes the following work types for natural gas distribution.New business gas inain and gas
service installation and the relocation/replacement of existing gas mains &gas services.
Activities intended to be part of the general work description include standard installation methods such as
trench,plow or HDD.The welding,fusing and general pipe handling required to complete the installation,
Pigging,testing,purging and gassing of the installed mains and services.The proper abandonment of any
retired main &services.The backfill and compaction of any required excavations.Permanent restoration of
any disturbed areas.The provision of traffic controi devices in the form of basic (detours,flagging,
extended closures,message boards etc.not included)work area protection..
This contract is a unit based.fee schedule.See attached Exhibit A-City of Waukee,IA Blanket Contract
Unit Pricing 2015.
Any work performed outside the scope of the Unit Price descriptions/definitions will be performed at the
labor &equipment rates also agi'eed to in Exhibit A.
Schedule of Work.Time is of the essence.Contractor shall provide Owner with any requested scheduling
information of Conh'actor's Work.A Schedule of Work,including that specified on the Work Request
issued under this agreement shall be prepared by Owner and may be revised as the Work progresses.
Contractor recognizes that reasonable changes may be made m the Schedule of Work and agrees to
cooperate with the Owner to accommodate these changes.
Contractor shall coordinate its work with all other contractors,subcontractors,and suppliers on the Project
so as not to delay or damage their performance,work,or the Project.
ARTICLE 4
Changes.Owner,without nullifying this Agreement,may request Contractor in writing to.make changes
to Contractor's Work.Adjustments in the scope of work,the negotiated price and/or in contract time
resulting fi'om such changes shall be set forth in a Change Order pursuant to the Contract Documents.
ARTICLE 5
Failure of Performance.Should Contractor fail to satisfy contractual de6ciencies within ten (10)working
days kom the receipt of Owner's written notice,then the Owner shall have the right to terminate this
agreement.
Neither party will be Hable for its failure to perform under this agreement if such failure arises out of causes
beyond their control and without fault or negligence of such party.
ARTICLE 6
Insurance.Prior to the acceptance of this contract,Conti'actor shall procure and maintain in force for the
duration of this contract,Worker's Compensation Insurance (at statutory levels),Comprehensive
Automobile Liability Insurance (not less than $1,000,000 per occurrence)and Comprehensive General
Liability Insurance (not less than 1,000,000 per occurrence and uot less than $2,000,000 in aggregate).
Owner shall be named as additional insureds on each ofthese policies,except for Worker's Compensation.
ARTICLE 7
Indemnification,Bach party (the "Indemnifying Party")shall indemnify,defend,and hold harmless the
other party and its afKates and subcontractors of any tier,and the directors,officers,employees,agents,of
each,Som and against any claim,demand,action,one,penalty,liability,judgment,loss,damage,injury,
cost and expense (including reasonable attorneys'fees)resulting from (a)injury to or death of any person;
or (b)damage to or loss or destruction of any real or tangible personal property,to the extent such claims
are caused by the negligenoe or intentional misconduct of the Indemnifying Party.
ARTICLE g
Warranty.The Contractor warrants its work against deficiencies and defects in worhnanship and agrees
to satisfy same for a period of twelve (12)months from the date of work completion.
ARTICLE 9
Mutual Waiver of Consequential Damages.The parties waive all claims against each other for any
consequential,incidental,special,exemplary or punitive dainages (including but not limited to,loss of
actual or anticipated profits,revenues or product;loss by reason of shutdown or non-operatlon;increased
expense of inanufacturing,operation,borrowing or financing;loss of use,productivity or shop space;or
increased cost of capital),and regardless of whether any such claim arises out of breach of contract,
guarantee or warranty,tort (including negligence and professional negligence),product liability,indemnity,
contribution,strict liability or any other legal theory.
ARTICLE 10
Safety.The Contractor,its agents,employees,materialmen,and subcontractors will perform all work on
the project.in a safe and responsible manner,in particular,Contractor shall comply with all specific safety
requirements promulgated by any government authority,inchiding without liinitation the requirements of
the Occupational Safety and Health Act of 1970,the Construction Safety Act of 1969 and all standards and
regulations which have been or shall be promulgated by the party's or agency's requirements,standards
and regulations,and require and be directly responsible for compliance therewith on the part of its said
agents,employees,materialnteu.and subcontractors,and shall directly receive,respond to,defend,and be
responsible for all citations,assessments,fines or penalties.
The Contractor shall have in place and upon request of the owner provide a copy of the following prograins
that meet or exceed the Owner programs identified in the??epartment of Transportation (DOT)code:
a.PHMSA.Compliant Anti-Drug Program
b.PI%ISA Compliant Alcohol Testing Program
c.DOT Compliant Operator Qualification Program (OQ)
In witness whereof,the parties have executed this Agreement on the day and year first written above and
that each person executing this agreement warrants and represents that he or she is authorized to execute
this Master Service Contract on behalf of the painty for whom be or she has signed,and that he or she has
the legal authority to bind the party for whom he or she has signed to all the terins,conditions and
provisions set foith herein.
Owner:City of Waukee,Iowa
William F.Pear
Printed Name
nature
Title
Contractor:Q3 CONTRACTING,INC.
Printed Naine
Signature
Title
4 v~
0 I
~'I ~0 I ~~I
II ~-~I
II ~-~~
0 II ~-~I
J ~II ~~I
II ~.~~
II t-~~
i ~
i ~
~I I ~~
II ~-~~~I
I ~~I
I ~'~~-~~
~~II -~~
h ~0
Q&
'9F „'"ht™iP,W
~II ~
~-II
0 ~II ~
-I -il ~I ~0
0 ~
~II
-I -II ~~~
~I
~~
~II
~-il
~II
~~~
-~-II ~~
~II
~-II ~I ~~
~'hat ~~~I
'~~-i ~~~~rherrshrhihlehhsehr~-
0 0 '0
~~
~II
I -II ~~~
s I ~
~II I"0 ~
lr'll
0 ~
~~
~II
-I -~I
~-II ~~~
~~I
I ~I
~I
I;r ll
~~
~~
~II
~I ~
I:I II
I s
~~~
~-II 'I ~~
~~~
5 I
~I
I ~~~
J ~s ~~s 5 ~
5 s
~--~~I ~-~~
I I+I~Is '55 ~-I I ~''~5~@ii~~f{,I 'I f I g
'.-{I';-v.~
I e .o 5 ~
~I -~.~e -'~~0 ~II
~~~~
I -5 .~~~
~s ~s
~~
I{=~
~~
~{{
I
{{o 5 I.5 I Y I
'J~','P
J ~
~I ~
~~s
~~
I I ~
CI
I
~~
~.I
{
~'~~~"
~~'-~5 ~~..I .I ~
'I
I II
~II
'll ~I
II
~II
II
~I
s s s ~
~~-
~~~
~~
~-s
~.'"s I ~~~s .s s
I 5 ~
I ~~~~~~~
s .~~:I-~.-~~
I ~'~~~~
~,s ~~I ~~~s
s ~~
~5 ~"~~~~
s .~~~~~
~~~~II
~~
"I I ~~~~~~~~
~~"~~~~~~
I ~I ~~~I ~
~~~I ~'~-~~~~~~
~~,IN
P ~~~
~I ~
~~'~~.~0
~~"~~
~~~I ~~
~s ~-l}o
~a ~a
~l ~
II s-
~I I ~
~I ~
~~
~~~~~
~~~~
~s
~~~~
~~~
~~-.~
~}-~
~)~
~~
~~
a-
~~4
~--o
~~~5
I ~
I ..-~-~
s ~~~
~~
Equipment Trailer
Pipe Trailer Stick
Pipe Trailer Coil
Vacuum Excavator
Pipe Straightner
Generator
Water Pump
Jumping Jack Tamper
Air Compressor with Tools
Weld Rig
~AI!&"a gj al:"'d e
tal'-'Pj'ajar'
i''plgf '',4t~gost&Nius%~Pg@~UIp
$100.78
$3.71